Tully Construction Co., A.J. Pegno Construction Co., J v. v. Canam Steel , 684 F. App'x 24 ( 2017 )

16-1324-cv
Tully Construction Co., A.J. Pegno Construction Co., J.V. v. Canam Steel Corp.
UNITED STATES COURT OF APPEALS
FOR THE SECOND CIRCUIT
SUMMARY ORDER
RULINGS BY SUMMARY ORDER DO NOT HAVE PRECEDENTIAL EFFECT. CITATION TO A
SUMMARY ORDER FILED ON OR AFTER JANUARY 1, 2007, IS PERMITTED AND IS GOVERNED
BY FEDERAL RULE OF APPELLATE PROCEDURE 32.1 AND THIS COURT=S LOCAL RULE 32.1.1.
WHEN CITING A SUMMARY ORDER IN A DOCUMENT FILED WITH THIS COURT, A PARTY
MUST CITE EITHER THE FEDERAL APPENDIX OR AN ELECTRONIC DATABASE (WITH THE
NOTATION “SUMMARY ORDER”). A PARTY CITING TO A SUMMARY ORDER MUST SERVE A
COPY OF IT ON ANY PARTY NOT REPRESENTED BY COUNSEL.
At a stated term of the United States Court of Appeals for the Second Circuit, held at the
Thurgood Marshall United States Courthouse, 40 Foley Square, in the City of New York, on the
23rd day of March, two thousand seventeen.
Present:
ROBERT D. SACK,
DEBRA ANN LIVINGSTON,
RAYMOND J. LOHIER, JR.,
Circuit Judges.
_____________________________________
TULLY CONSTRUCTION CO., INC., A.J. PEGNO
CONSTRUCTION CO., J.V.,
Petitioners-Cross Defendants-Appellees,
v. 16-1324
CANAM STEEL CORP.,
Respondent-Cross Claimant-Appellant.
_____________________________________
For Petitioners-Cross Defendants-Appellees: TIMOTHY T. COREY, Hinckley Allen &
Snyder LLP, Hartford, CT; Christopher V.
Fenlon, Hinckley Allen & Snyder LLP,
Albany, NY
For Respondent-Cross Claimant-Appellant: CELIA GOLDWAG BARENHOLTZ, David J.
Bright, Cooley LLP, New York, NY
1
UPON DUE CONSIDERATION WHEREOF IT IS HEREBY ORDERED,
ADJUDGED, AND DECREED that the judgment of the district court is AFFIRMED.
Appellant Canam Steel Corporation (“Canam”) appeals from a judgment of the United
States District Court for the Southern District of New York (Gardephe, J.), entered on March 30,
2016, granting the motion of Appellee Tully Construction Company, Inc. (“Tully”) to confirm an
arbitration award and denying Canam’s cross-motion to vacate the award. We assume the
parties’ familiarity with the facts, procedural history, and specification of issues on appeal.
I. Background
In 2002, New York State hired Tully to replace a portion of the Whitestone Bridge, a
suspension bridge that spans the East River and connects the Bronx and Queens via Interstate
678. Tully hired Eastern Bridge LLC (“Eastern Bridge”), a steel fabricator and non-party to
this action, to produce and deliver several million dollars’ worth of structural steel for the Project
under a “Purchase Order.” After disputes arose concerning Eastern Bridge’s compliance with
the terms of the Purchase Order, Tully and Eastern Bridge entered into a May 15, 2007
“Completion Agreement,” which contained a revised delivery schedule and an arbitration clause.
Two months later, Eastern Bridge and Canam entered into an “Asset Purchase Agreement,”
pursuant to which Canam acquired some of Eastern Bridge’s assets and liabilities and took over
Eastern Bridge’s performance in connection with the Whitestone Bridge project.
After disputes arose between Tully and Canam about the timeliness of deliveries, Tully
served Canam with a demand for arbitration in April 2008. The parties thereafter entered into a
“Delivery Agreement.” The Delivery Agreement provided yet another revised schedule and
required that Tully deposit money claimed by Canam into an escrow account. In addition, the
agreement contained an arbitration clause with a chosen venue of New York. An arbitration
2
eventually ensued. After 17 days of hearings, testimony from 11 witnesses, and the
introduction of more than 800 exhibits, Arbitrator John J. Krol issued an Original Award on
April 24, 2013 and a Revised Award on June 4, 2015. Krol awarded Tully $6,883,936.00 and
Canam $366,914.00. Tully moved to confirm the Revised Award in the district court, and
Canam cross-moved to vacate. The district court granted Tully’s motion and denied Canam’s
motion.
II. Discussion
A. Standard of Review
“This Court reviews a district court’s decision to confirm or vacate an arbitration award
de novo for questions of law,” and for clear error for findings of fact. Kolel Beth Yechiel
Mechil of Tartikov, Inc. v. YLL Irrevocable Trust, 729 F.3d 99, 103 (2d Cir. 2013). “When a
party challenges the district court’s review of an arbitral award under the manifest disregard
standard, we review the district court’s application of the standard de novo.” Porzig v.
Dresdner, Kleinwort, Benson, N.A. LLC, 497 F.3d 133, 138 (2d Cir. 2007) (quoting Wallace v.
Buttar, 378 F.3d 182, 189 (2d Cir. 2004)).
B. Motion to Confirm/Cross-motion to Vacate
“Following issuance of an arbitration award, § 9 of the Federal Arbitration Act (‘FAA’)
provides that a party may apply to a district court ‘for an order confirming the award, and
thereupon the court must grant such an order unless the award is vacated, modified, or corrected
as prescribed in [S]ections 10 and 11 of this title.’” STMicroelectronics, N.V. v. Credit Suisse
Sec. (USA) LLC, 648 F.3d 68, 74 (2d Cir. 2011) (quoting 9 U.S.C. § 9). A party moving to
vacate an arbitration award has a “very high” burden of proof to avoid confirmation. D.H.
Blair & Co., Inc. v. Gottdiener, 462 F.3d 95, 110 (2d Cir. 2006). Indeed, courts “play only a
3
limited role when asked to review the decision of an arbitrator.” United Paperworkers Int’l
Union, AFL-CIO v. Misco, Inc., 484 U.S. 29, 36 (1987). “[O]nly a ‘very narrow set of
circumstances delineated by statute and case law’ permit vacatur.” Porzig, 497 F.3d at 138
(quoting Duferco Int’l Steel Trading v. T. Klaveness Shipping A/S, 333 F.3d 383, 388 (2d Cir.
2003)). Under Section 10 of the FAA, an arbitration award may be vacated if, inter alia, it was
procured by corruption or fraud, or the arbitrators “exceeded their powers.” 9 U.S.C. § 10(a).
The Second Circuit recognizes two additional bases for vacatur: if the award “was rendered ‘in
manifest disregard of the law,’” Schwartz v. Merrill Lynch & Co., Inc., 665 F.3d 444, 451 (2d
Cir. 2011) (quoting T.Co Metals, LLC v. Dempsey Pipe & Supply, Inc., 592 F.3d 329, 340 (2d
Cir. 2010)), or “the terms of the [parties’ relevant] agreement[s],” id. at 452 (second alteration
added) (quoting Yusuf Ahmed Alghanim & Sons v. Toys “R” Us, Inc., 126 F.3d 15, 23 (2d Cir.
1997)). However, only “a barely colorable justification for the outcome reached” by the
arbitrator is necessary to confirm the award. Landy Michaels Realty Com. v. Local 32B-32J,
Service Employees Int’l Union, 954 F.2d 794, 797 (2d Cir. 1992) (quoting Andros Compania
Maritima, S.A. v. Marc Rich & Co., 579 F.2d 691, 704 (2d Cir. 1978)).
1. Manifest Disregard
On appeal, Canam claims that the arbitrator’s award was rendered in manifest disregard
of the law and the terms of the parties’ relevant agreements. First, Canam contends that the
arbitrator disregarded an order issued by the New Hampshire Superior Court (“NH Order”) in
connection with a declaratory judgment suit commenced by Canam in December 2009. The
order states that, as between Canam and Eastern Bridge, Canam did not assume liability for any
breach of contract that occurred prior to the signing of the Asset Purchase Agreement on July 16,
4
2007.1 The NH Order also included language about the impact of the Delivery Agreement on
the APA. Arbitrator Krol declined to afford this language preclusive effect in the arbitration
under res judicata or collateral estoppel principles because it was “properly considered
superfluous obiter dicta.” J.A. 242 (citing Pollicino v. Roemer & Featherstonhaugh P.C., 277
A.D.2d 666, 668 (N.Y. App. Div. 3rd Dep’t 2000) (“Language that is not necessary to resolve an
issue, however, constitutes dicta and should not be accorded preclusive effect[.]”)). The district
court concluded that there was “ample support for the arbitrator’s ruling” on this issue, citing the
NH Order’s explicit limitation to contractual relationship between Eastern Bridge and Canam.
S.P.A. 55. We agree. On appeal, Canam repeats arguments that it made to the district court
and does not engage with the authority that the arbitrator cited. And even if Canam could
persuade this Court that the arbitrator made a legal error, manifest disregard “clearly means more
than error or misunderstanding with respect to the law.” Wallace, 378 F.3d at 189. We see no
reason to disturb the district court’s conclusion.
Second, Canam argues that the arbitrator manifestly disregarded the terms of the “Letter
Agreement” between the parties, an allegedly binding contractual modification that extended the
steel delivery schedule for the project. According to Canam, the arbitrator miscalculated the
length of Canam’s delay and overestimated Tully’s damages as a result. Tully responds, as it
did during the arbitration, that the Letter Agreement was nothing more than an
agreement-to-agree and is therefore unenforceable under New York law. The district court
stated that “the effect of the Letter Agreement on the parties’ obligations was a matter for the
arbitrator to decide based on the evidence before him,” and that, upon review, there is no
1
The New Hampshire Supreme Court affirmed the NH Order, stating that “this litigation is limited to
resolving the dispute between Canam and Eastern Bridge under the terms of the [APA].” J.A. 162.
5
evidence in the record suggesting that there is “no colorable justification for the arbitrator’s
decision.” We again agree. The Letter Agreement contains qualified terms such as “Canam’s
proposed agreement,” an “agreement in principle,” and “tentative” delivery dates. J.A. 86. In
addition, the agreement itself states that the parties “agree to adopt an agreement,” J.A. 87, and
that the “change of delivery schedule is without prejudice to Tully’s expectation that the steel
would be delivered pursuant to the time frame included in [the 2003 Purchase Order].” J.A. 86.
In such circumstances, we cannot conclude that “the arbitrator[] so misread [the Letter
Agreement’s] provisions as to empower a court to set aside the award.” Nat’l Cash Register
Co. v. Wilson, 8 N.Y.2d 377, 383 (1960); see also Major League Baseball Players Ass’n v.
Garvey, 532 U.S. 504, 509 (2001) (per curiam) (“When an arbitrator resolves disputes regarding
the application of a contract, and no dishonesty is alleged, the arbitrator’s ‘improvident, even
silly, factfinding’ does not provide a basis for a reviewing court to refuse to enforce the award.”
(quoting Misco, 484 U.S. at 39)).
Third, Canam claims that the arbitrator had no basis to impose pre-APA liability on
Canam. Canam points to Section 2.03(ii) of the APA, in which the buyer (Canam) assumed the
obligations of the seller (Eastern Bridge) under the “Contracts . . . (other than liabilities or
obligations attributable to any failure by Seller[, Eastern Bridge,] to comply with the terms
thereof).” J.A. 310. But even assuming, arguendo, that construing this provision in the APA
to permit the imposition of pre-APA liability on Canam would be in manifest disregard of the
law, it is not clear that the arbitrator even imposed pre-APA liability on the Appellant.
Canam’s speculation about why the arbitrator awarded varying percentages of each of Tully’s
claims provides no basis for concluding that the arbitrator manifestly departed from the terms of
the parties’ agreements. Indeed, there are many reasons that the arbitrator might have decided
6
to award a certain amount of each claim: whether the alleged damages were “a result of
non-concurrency, were not foreseeable, were not anticipated, are excusable, and are
compensable.” J.A. 544. Moreover, variation in the credibility and amount of evidence of
damages could have resulted in more or less being awarded for certain claims. The arbitrator,
based on the extensive evidence before him, concluded that Canam’s breach was responsible for
some of Tully’s claimed damages and awarded Tully the amount he believed it was due. And
to the extent that Canam is arguing that the arbitrator “manifestly disregarded” the evidence that
Eastern Bridge was actually liable for Tully’s damages, we agree with the district court that this
Circuit “‘does not recognize manifest disregard of the evidence as [a] proper ground for vacating
an arbitrator’s award.’” Wallace, 378 F.3d at 193 (quoting Success Sys., Inc. v. Maddy
Petroleum Equip., Inc., 316 F. Supp. 2d 93, 94 (D. Conn. 2004)).
2. Reasoned Award
Canam next claims that the arbitrator did not issue a reasoned award. A reasoned award
is something short of findings of fact and conclusions of law but more than a simple result.
Leeward Constr. Co., Ltd. v. Am. U. of Antigua–Coll. of Med., 826 F.3d 634, 640 (2d Cir. 2016).
In other words, it requires
something more than a line or two of unexplained conclusions, but something less
than full findings of fact and conclusions of law on each issue raised before the
panel. A reasoned award sets forth the basic reasoning of the arbitral panel on
the central issue or issues raised before it. It need not delve into every argument
made by the parties.
Id.
7
Canam argues that the arbitrator did not explain (1) the fact that he awarded 53.125
percent of the damages for two of Tully’s claims and higher percentages on two others and (2)
why he rejected Canam’s defense that “Canam had no pre-APA liability to Tully by virtue of
New Hampshire law and the APA.” Blue Brief at 44. The district court concluded that the
arbitrator sufficiently explained why he awarded certain amounts on each claim. We agree.
The arbitrator “need not delve into every argument made by the parties” in order to issue a
reasoned award. Leeward, 826 F.3d at 640. Any award that “set[s] forth . . . the key factual
findings supporting its conclusions” is a reasoned award. Id. Here, the arbitrator laid out a
factual history of the parties’ dealings, and—after concluding that Canam delivered material
late—discussed why Tully was entitled to damages on some claims and not others. In sum, the
arbitrator issued a reasoned award.
3. Damage Calculation
Finally, the arbitrator awarded Tully $6,517,022, the “initial award . . . less the amount
that Claimant may now reimburse itself from escrow (approximately $961,100.00), with interest
on the remaining amount; . . . .” J.A. 552. Canam argued to the district court that the “initial
award” should be reduced by the principal amount in escrow ($961,100.00) and accrued interest,
and that the interest should be calculated at the time the money is withdrawn from the escrow
account. Tully, in contrast, argued that the “initial award” should be reduced by the principal
alone. The district court concluded that “there [wa]s no interpretation of [the Delivery
A]greement under which Canam Steel Corp. would be entitled to the interest earned on the
escrowed funds.” J.A. 809. Thus, Canam was entitled to a credit equivalent to only the
principal amount in the escrow, not the interest. Id.
8
On appeal, Canam argues that the district court found ambiguity in the arbitrator’s
language where none existed. According to Canam, the “plain language” of the arbitrator’s
order indicates that the “initial award” should be reduced by the total amount in the escrow
account at the time of withdrawal. We disagree. The arbitrator did not state that Tully may
reimburse itself with everything in the escrow account at the time the money is withdrawn, but
rather that Tully was entitled to “the amount that [it] may now reimburse itself from escrow.”
J.A. 552. In addition, the arbitrator clarified that the amount was $961,100.00. We agree with
the district court that giving the interest earned on the Escrow Fund to Canam in the form of a
credit contravenes the Delivery Agreement. Therefore, Canam is entitled to reduce the amount
it owes to Tully by only the principal in the escrow account.
III. Conclusion
We have considered Canam’s remaining arguments and find them to be moot or without
merit. Accordingly, we AFFIRM the judgment of the district court.
FOR THE COURT:
Catherine O’Hagan Wolfe, Clerk
9