Military Aircraft Parts ( 2016 )


Menu:
  •                ARMED SERVICES BOARD OF CONTRACT APPEALS
    Appeal of --                                    )
    )
    Military Aircraft Parts                         )      
    ASBCA No. 60009
    )
    Under Contract No. SPM4A7-l l-M-Dl 11           )
    APPEARANCE FOR THE APPELLANT:                          Mr. Robert E. Marin
    President
    APPEARANCES FOR THE GOVERNMENT:                        Daniel K. Poling, Esq.
    DLA Chief Trial Attorney
    Edward R. Murray, Esq.
    Jason D. Morgan, Esq.
    Trial Attorneys
    DLA Aviation
    Richmond, VA
    OPINION BY ADMINISTRATIVE JUDGE O'SULLIVAN
    Military Aircraft Parts (MAP) appeals from a contracting officer's final decision
    denying its claim for breach of contract. The parties have submitted the appeal for
    decision on the written record pursuant to Board Rule 11. 1 Both entitlement and quantum
    are at issue. We have jurisdiction pursuant to the Contract Disputes Act of 1978 (CDA),
    
    41 U.S.C. §§ 7101-7109
    . We sustain the appeal in part.
    FINDINGS OF FACT
    1. Purchase Order No. SPM4A7-l l-M-Dl 11 (the contract) was issued by the
    Defense Logistics Agency Aviation (DLA Aviation) field office, Richmond, Virginia,
    to MAP on 18 November 2010 (R4 tab 1). The government sought to acquire one first
    article and six production units of a steel flap track liner for the A-10 aircraft (id. at 3,
    8-10). The contract identifies this part as a Critical Application Item (id. at 4 ). The
    total price of the contract, for first article manufacture and testing and six production
    parts, was $7,550.00 (id. at 1). Section B of the contract contains first article testing
    instructions, which provide in pertinent part:
    5. MATERIAL PROCESSING, INCLUDING FINISH
    REQUIREMENTS (PLATING, CASTING, FORGING,
    1
    MAP originally elected to proceed under Board Rule 12.2, small claims expedited
    procedure. MAP subsequently elected to remove the appeal from the Board's
    Rule 12 docket in order to extend the time available for discovery.
    HEAT TREATMENT, WELDING, INSPECTION,
    ANODIZE, PAINTING, ETC.) UTILIZED IN THE
    MANUFACTURE OF FIRST ARTICLE ITEMS SHALL
    BE IDENTIFIED AND CERTIFIED ALONG WITH A
    COPY OF MATERIAL PURCHASE REQUESTS AS
    CONFIRMING TO APPLICABLE DATA
    REQUIREMENTS. A COPY OF THE PURCHASE
    ORDER CERTIFYING THE PROCESS
    ACCOMPLISHED AT OTHER THAN CONTRACTOR
    FACILITY SHALL BE INCLUDED.
    (Id. at 3) The applicable drawings specify the application of cadmium plating and
    epoxy-polyamide primer as part of the manufacturing process (R4, tab 19 at 7).
    2. The contract contained the Federal Acquisition Regulation (FAR) 52.209-4,
    FIRST ARTICLE APPROVAL-GOVERNMENT TESTING (SEP 1989) clause, with its
    AL TERNA TE I (JAN 1997). The clause provides in pertinent part:
    (b) Within 120 calendar days after the Government
    receives the first article, the Contracting Officer shall
    notify the Contractor, in writing, of the conditional
    approval, approval, or disapproval of the first article. The
    notice of conditional approval or approval shall not relieve
    the Contractor from complying with all requirements of the
    specifications and all other terms and conditions of this
    contract. A notice of conditional approval shall state any
    further action required of the Contractor. A notice of
    disapproval shall cite reasons for the disapproval.
    (c) If the first article is disapproved, the Contractor,
    upon Government request, shall submit an additional first
    article for testing. After each request, the Contractor shall
    make any necessary changes, modifications, or repairs to
    the first article or select another first article for testing. All
    costs related to these tests are to be borne by the
    Contractor, including any and all costs for additional tests
    following a disapproval. The Contractor shall furnish any
    additional first article to the Government under the terms
    and conditions and within the time specified by the
    Government. ...
    (d) If the Contractor fails to deliver any first article
    on time, or the Contracting Officer disapproves any first
    article, the Contractor shall be deemed to have failed to
    2
    make delivery within the meaning of the Default clause of
    this contract.
    (h) Before first article approval, the acquisition of
    materials or components for, or the commencement of
    production of, the balance of the contract quantity is at the
    sole risk of the Contractor. Before first article approval,
    the costs thereof shall not be allocable to this contract for
    (1) progress payments, or (2) termination settlements if the
    contract is terminated for the convenience of the
    Government.
    (R4, tab 1 at 14)2 The contract also contains a DLA clause with additional requirements,
    52.209-9018, FIRST ARTICLE - GOVERNMENT TEST-ADDITIONAL REQUIREMENTS (SEP
    2008) DLAD (id.).
    3. The contract required delivery of the first article to the government for
    testing by 17 May 2011, 180 days after award (R4, tab 1 at 2). It is undisputed that
    MAP did not deliver the first article by this date; the first article was delivered to the
    government for testing on 30 January 2012 (R4, tab 37). 3 Government testing of
    MAP's first article resulted in a discrepancy report that was attached to a notice
    provided by the contracting officer to MAP on 15 May 2012 that its first article was
    disapproved (R4, tabs 4, 5). The only discrepancy noted after testing and inspection
    was with respect to the holes drilled in the part to facilitate its attachment to the flap
    track-the contract called for the holes to be .190" to .194" in diameter, but the report
    stated that the actual diameter was ".195 - .196 [in] twelve places" (id.). 4
    4. The government's structures engineer who replaced the engineer responsible
    for reviewing the first article submitted by MAP is familiar with the A-10 wing flap
    system and provided the following general information about the holes in the flap
    liner. Aircraft mechanics use the 12 holes to mount the liner, with fasteners, to an
    underlying aluminum section which is traversed by the roller that extends and retracts
    the wing flaps of the aircraft. If the liner were not securely fastened and were to
    detach from the mating section below, the roller would be likely to damage that
    section and potentially cause the wing flap not to operate correctly. In addition, if the
    2
    FAR 52.209-4 is not set forth in full text in the contract document.
    3
    The record before us does not indicate that the government took any action with
    respect to the missed delivery date. There is no indication that a new delivery
    date was ever established.
    4
    A second discrepancy with respect to the certification package was corrected on
    14 May 2012 (id.).
    3
    liner holes are too large, the mechanic attaching the liner may not be able to use it as a
    template for drilling holes in the mating part and may not be able to use the specified
    fasteners. (Gov't br., ex. A, Casey Thurber decl. (Thurber decl.) iii! 1-4) However, the
    government has presented no evidence that the nonconforming holes in MAP's first
    article were large enough to actually present the potential problems described.
    5. At MAP's request, quality assurance representatives (QARs) Randall Fritz
    and Greg Keeler from the Defense Contract Management Agency (DCMA) visited
    MAP's facility on 20 June 2012 to witness an inspection of the returned part (gov't br.,
    ex. C, Randall Fritz decl. (Fritz decl.) iii! 2, 3). Contrary to the discrepancy report,
    only 3 (out of 12 total) holes were found to be out oftolerance-i.e., measuring .195"
    to .196" in diameter (R4, tab 6). The remainder measured .190" to .194" in diameter
    (R4, tab 40). At the time, Mr. Marin of MAP pointed out that the out-of-tolerance
    holes were missing paint, and stated that this condition could have been caused by
    forcing gauge pins 5 through the holes, thereby removing the paint and enlarging the
    holes (Fritz decl. ii 5). Mr. Fritz responded that Mr. Marin's theory was plausible but
    unlikely, and offered him an opportunity to demonstrate on another part. Mr. Marin
    declined because he did not want to destroy a part. (Id.; R4, tab 9 at 1)
    6. The same day, 20 June 2012, Mr. Marin emailed DLA contract administrator
    Lisa Hardy, noting that paint was missing from the holes that were measured to be out of
    tolerance, and further stating that MAP suspected that the part "was in tolerance and
    acceptable per drawing when submitted and forceful inspection at the ESA caused by
    forcing a gage pin thru the hole occurred." 6 Mr. Marin asserted that over a hundred holes
    in parts made at the same time were in tolerance and did not have paint removed from the
    holes. He requested permission to do a resubmittal at no cost. (R4, tab 6 at 1)
    QAR Fritz replied to this email, confirming to Ms. Hardy that three of the holes were out
    of tolerance, and stating "I would concur with you, if you should decide to allow a no
    cost resubmittal" (id.).
    7. The ESA engineering technician who performed the measurement of the
    holes in the first article provided a declaration in which she confirmed that she "found
    the holes to be in the .195" to .196" range." She denied enlarging the holes or forcing
    gauge pins through the holes, but did state that it is possible that her use of the gauge
    pin could have removed paint from the holes. In her opinion, such a result would be
    "typical, but irrelevant to the inspection. The inspection is for the diameter of the
    metal, not the paint." (Gov't br., ex. B, Julie Morse decl. (Morse decl.) iii! 1-4)
    Engineer Thurber backs up Ms. Morse's opinion in this regard, declaring that:
    5
    The Board will refer to these measuring instruments·as "gauge pins," following the
    dictionary preferred spelling of the word "gauge," but in the record the spelling
    used is most often "gage."
    6
    ESA refers to the Engineering Support Activity at Hill Air Force Base, Utah. The
    ESA conducted the first article inspection at issue in this appeal.
    4
    It is .. .irrelevant that the paint was removed from any of the
    holes in the part. The inspection should be measuring the
    diameters of the metal, not paint. Paint is not a structural
    component and obviously does not have the structural
    integrity of steel. Paint will not hold a fastener in place.
    Likewise, a part with oversized holes cannot be repaired by
    adding paint to the holes. This will not repair the structural
    integrity of the part.
    (Thurber decl. ii 5)
    8. Although Ms. Morse does not in her declaration provide any details about
    how she conducted her inspection, there is evidence in the record that she used gauge
    pins during the inspection process (R4, tab 38 at 5).
    9. On 22 June 2012, Mr. Fritz issued a Corrective Action Request (CAR) to MAP,
    requesting that MAP respond on or before 5 July 2012 with its analysis of the cause of
    the dimensional nonconformance and the action proposed to be taken to prevent a
    re-occurrence (R4, tab 7).
    10. On 25 June 2012, MAP quality inspector Alberto Valenzuela conducted his
    own inspection of the holes in the rejected part. He recorded measurements from .190
    to .196". (R4, tab 40)
    11. The previous year, on 9 November 2011, Mr. Valenzuela had inspected the
    same part prior to sending the part to the government for inspection, and recorded a
    hole diameter of .194" at Step 4 of the manufacturing process (R4, tab 33). That same
    day, 9 November 2011, another MAP inspector performed an inspection of the same
    part at Step 5 of the manufacturing process and recorded the hole diameter as .191"
    (R4, tab 34). 7 Subsequently, on 21 November 2011, a third MAP inspector conducted
    an inspection on a sample of four parts out of a production run of 13 parts at Step 5 of
    the manufacturing process. 8 This inspector recorded a hole diameter of .191" for the
    four inspected parts. (R4, tab 35) Finally, on 30 January 2012, government
    QAR Gordon Gregory signed off on the First Article Test Report conducted by MAP
    prior to shipping the first article for government testing, commenting:
    7
    From the information available in the record, it appears that Step 4 involves the
    drilling of the holes and Step 5 involves "MACHINE DE-BURR PER G-FlOl."
    Both of these steps precede the application of the required coating and primer.
    (R4, tab 36)
    8 MAP elected to manufacture the first article, the six production parts, and additional
    parts, for a total of one first article and twelve production parts, in one
    production run prior to first article approval (R4, tab 48 at 14).
    5
    VERIFIED CALIBRATION, VERIFIED PPP&M,
    REVIEWED CERT PACKAGE, REVIEWED
    INSPECTION RECORDS, REVIEWED CONTRACT
    FOR EXCEPTIONS, WITTINESS [sic] DIMENSIONAL
    INSPECTION & METHODS, RECOMMEND FAT
    APPROVAL[.]
    (R4, tab 37 at 2) The dimension recorded for hole diameter in the FAT Report was
    .191" for a sample of 4 out of 13, as inspected on 21 November 2011 (id. at 3 7).
    12. On 19 July 2012, MAP responded to the DCMA CAR. MAP asserted that
    the root cause of the nonconformance was damage caused by the government while
    inspecting the part, pointing out that "144 holes in parts we have in stock made at the
    same time were in tolerance and did not have paint removed from the holes." MAP
    requested the opportunity to submit one of the production parts as a new first article
    and requested that the government use "reasonable care" in inspecting it. (R4, tab 8)
    Mr. Fritz responded on 23 July 2012 that MAP's response was unacceptable. He
    stated: "I offered you the chance to prove your theory if you were willing to destroy
    one of your stock parts at no expense to the government, to demonstrate. You
    declined." (R4, tab 9 at 11) Mr. Fritz apparently agreed with Mr. Marin that forcing a
    gauge pin through the hole, thereby removing the paint, would destroy the part.
    13. On 19 July 2012, Ms. Lisa Hardy of DLA Aviation responded to
    Mr. Marin's 20 June 2012 email (finding 6), requesting that he confirm MAP's
    willingness to pay the first article re-testing fee of $651.07 as well as consideration of
    $1,325.55 to re-establish the first article test date to 31August2012. She further
    informed him that a no-cost cancellation of the order was an available option. He
    responded the same day, stating that "[w]e certainly feel strongly this was a
    Government caused disapproval and hope you will consider DCMA' s
    recommendation to resubmit at no additional cost. If not, then this is reluctantly
    acceptable." (R4, tab 13 at 2-3)
    14. Both parties agree that on 20 June 2012 in the presence of Messrs. Fritz and
    Keeler, and again on 24 July 2012 in the presence of Mr. Robert Presley, DCMA
    supervisory quality assurance specialist, MAP employees pulled production parts from
    stock, used "go/no-go" gauge pins on them, and represented to the government
    representatives that the parts were compliant (Fritz decl. ii 4; gov't hr., ex. D,
    Robert Presley decl. (Presley decl.) ii 3). It does not appear from the record that the
    results of these inspections of the production parts were recorded, and both Mr. Fritz and
    Mr. Presley stated they do not know the sizes of the gauge pins that were used (Fritz decl.
    ii 4; Presley decl. ii 3). None of these government representatives either questioned any
    of the reported results, or performed any inspection themselves, despite having the
    opportunity to do so (id.).
    6
    15. From the record, there appear to be at least two different ways of inspecting
    the dimensional compliance of holes: (1) using go/no-go gauge pins; and (2) actually
    measuring the holes. The go/no-go process was described by Mr. Valenzuela, a MAP
    inspector with over 30 years of experience, as follows:
    In my inspection I prefer to perform what I call a "hard
    gage" inspection of the parts. This involves the use of two
    gage pins, a go and a no-go pin. For the .190/. l 94"
    diameter I would use a .190" and make sure it goes into all
    the holes. Finally I would use a .194" and check to see it
    does not go into any of the holes (no-go condition). This
    shows passing results.
    (App. supp. R4, tab 110, Valenzuela decl. ~~ 4, 6) Actually measuring the specific
    dimension of a hole appears to be more time-intensive and was described by Mr. Valenzuela
    as more likely to enlarge the holes than go/no-go inspection. Mr. Valenzuela stated:
    Measuring each and every hole in a part like this [referring
    to the flap track liner] can be done, but it takes a lot of time
    and can progressively make the hole larger, so I prefer not
    to do this.
    (Id. ~ 7) MAP also submitted for the record independent industry materials indicating
    that the use of go/no-go pin or plug gauges is an accepted method for inspecting the
    dimensional compliance of drilled holes on a pass/fail basis. For instance, the Meyer
    Gage Catalog states that:
    A GO gage is used to check the lower limit of a hole. A
    NOGO gage is used to check the upper limit of a hole. If the
    GO gage enters the hole and the NOGO gage is unable to
    enter, the design specifications of the hole have been met.
    (R4, tab 108 at 3) The same source cautions that such gauges are used to inspect the holes
    for pass/fail compliance only, and will not measure the exact size of the hole (id. at 4).
    16. On 25 March 2013 (there is no explanation in the record of what occurred, if
    anything, during the intervening eight months), DLA contracting officer (CO) Janice Hicks
    issued a show cause letter to MAP, inviting MAP to submit information bearing on
    whether the contract should be terminated for default, or a new delivery schedule should be
    established, within 10 days (R4, tab 11 ). MAP responded on 1 April 2013 that it had
    requested a no-cost resubmission and that it had enough parts in stock to immediately ship
    a first article and all production parts. It reiterated its position that the rejected first article
    was damaged during government inspection. (R4, tab 12 at 2) On 2 April 2013, CO Hicks
    7
    responded that the government could not approve a no-cost first article resubmittal unless
    MAP provided evidence of the rejected part being damaged by the government (id.).
    CO Hicks' request for evidence of government damage drew the following response from
    QARFritz:
    QAR Keeler and myself inspected the rejected part with
    Military Aircraft Parts personnel when the part was
    returned. We did not see any "clear and convincing
    evidence" that the government caused damage to the part
    during their test.
    We did observe the part was nonconforming.
    Just to be clear, DCMA at no time has recommended a no
    cost FA resubmittal.
    (R4, tab 12 at 1)
    17. On 5 April 2013, Mr. Marin responded to CO Hicks's invitation to submit
    evidence that the rejected part was damaged by the government by offering to return
    the damaged part to DLA "along with the 12 production parts that are in tolerance and
    undamaged. This will provide proof and assure that production parts are in tolerance
    at the same time." (R4, tab 14 at 2) CO Hicks responded the following Monday,
    8 April:
    Rob
    You have one of 2 choices-
    1. You can resubmit the FAT samples and pay the cost for
    FAT resubmittal.
    2. DLA can proceed with Termination for Default.l91
    I need a decision no later than 16 April 2013. If no
    response is received, then I will surmise that your decision
    was for DLA to proceed with Termination for Default.
    On 17 April 2013, Mr. Marin responded that MAP agreed to the resubmittal and to pay
    the cost of re-testing. (R4, tab 14 at 1) That same day, Mr. Keeler emailed Mr. Marin
    and stated that MAP needed to make a new first article test part and could not use one
    9
    In accordance with FAR 49.504(a)(l), the contract did not contain FAR 52.249-8. Default
    (Fixed-Price Supply and Service) (or any other Default clause). The inclusion of this
    clause was not required pursuant to FAR 49.504(a)(l) since the contract amount did
    not exceed the simplified acquisition threshold. See FAR 2.101.
    8
    of the parts from the prior production run, because "your FAT failed government
    inspection so all parts you made on the same run as the FAT are considered bad also"
    (R4, tab 15 at 1-2).
    18. On 19 April 2013, DLA contract administrator Lee Skimin sent MAP contract
    Modification No. POOOO 1 (Mod. POOOO 1) containing a new CLIN and delivery date for
    the first article resubmittal (R4, tab 16 at 2, tab 2). Mr. Marin responded the following
    Monday, 22 April, that he was unsure how to proceed because:
    2. On 6/20/12 we worked with our QAR to inspect all the
    holes in the 12 remaining parts, which we would like to
    use as our FA exhibit. All items were acceptable.
    3. On 7/24/12 Randy's DCMA supervisor, Robert Presley,
    also came in and the same inspection was conducted. All
    holes were acceptable.
    4. DCMA now wants to reject the parts with holes they
    observed to be acceptable, per the email below [the
    referenced email appears to have been deleted in the copy
    provided by the government for the Rule 4 file].
    The attached contract page seems to give the Government
    the option to reject the parts, though this appears
    counterproductive and cost prohibitive. Making new parts
    obviously would require additional time and cost.
    Is this something to address with your agency or DCMA?
    I would certainly like to resolve this without further
    conflict with DCMA.
    (R4, tab 17 at 2) The "attached contract page" refers to Section B of Order
    No. SPM4A7-11-M-Dl 11, which contains an unnamed, unnumbered, undated clause
    providing as follows:
    SAMPLING:
    1. SAMPLING FOR INSPECTION AND TESTING
    SHALL BE IA W ANSI/ASQ Z.4-2008, DATED
    JAN 1, 2008. ANY ALTERNATE PLAN MUST BE
    APPROVED BY THE PCO. A SAMPLING PLAN
    THAT ACCEPTS ON ZERO DEFECTS IS
    REQUIRED.
    2. ANY DEFECTIVE ITEM DISCOVERED DURING
    INSPECTION MAY BE CAUSE FOR REJECTION
    9
    OF THE ENTIRE CONTRACT QUANTITY.
    CRITICAL APPLICATION ITEM.
    (R4, tab 17 at 7, tab I at 4)
    19. In response, CO Hicks emailed Mr. Marin on 23 April 2013, stating:
    We cannot accept a new FAT sample from production
    quantities where the FAT failed previously. The reason
    being is your FAT failed government inspection so all
    parts you made on the same production run as the FAT are
    considered bad parts. That is a risk that you assumed when
    you manufactured the entire production quantity at the
    same time that you produce[ d] the FAT sample. You will
    need to produce a new FAT sample and if it passes, then
    you will need to produce new quantities.
    (R4, tab 17 at 1) Neither CO Hicks nor Mr. Keeler specified any contract term
    underlying their refusal to accept a new first article made from the same production
    run as the disapproved first article.
    20. On 2 May 2013, MAP and the government executed bilateral Mod. POOOOl
    establishing a first article resubmittal date of 24 October 2013 (R4, tab 2). Mod. POOOOl
    states in pertinent part:
    3. To re-submit a First Article, reference DLA Aviation,
    FAWA Disapproval Letter, dated 19 JUN 2012. First
    Article re-submission is as follows: a. Revise the delivery
    date on CLIN 0002, formerly CLIN 9906 to 24 OCT 2013,
    for First Article re-submission. b. Contractor shall provide
    DLA Aviation with proof of delivery (DD250) and
    shipping documents that the First Article re-submission
    was shipped by the date above.
    4. Revise the delivery date on CLIN 0001, Production
    Units, as indicated- 22 APR 2014- due to the time
    extension for the First Article re-submission.
    5. Pursuant to FAR 52.209-4, the related costs are:
    Re-Testing Charges: $651.07
    Administrative Costs and Time Extension: Waived
    Total: $651.07
    10
    Consideration in the amount of $651.07 is accepted for this
    modification. For invoicing purposes, the contract value
    will not be changed. Therefore, when invoicing the
    contractor's invoice should NOT be adjusted to reflect this
    modification. To effectuate this modification, the payment
    office will offset the amount of this modification against
    any outstanding payments due, potentially including other
    contracts.
    6. Pursuant to FAR 52.209-4 and the General Provision
    Clauses, if the First Article re-submission is not delivered
    by the date above, or if the First Article is disapproved
    (second disapproval), this contract may be terminated in its
    entirety at no cost to the Government.
    Purpose of this modification is to authorize the Contractor
    to re-submit the First Article, accept the Contractor's
    consideration and to revise the delivery dates for the First
    Article and for Production, due to the Contractor's decision
    to re-submit a previously disapproved First Article.
    (R4, tab 2 at 2) Mod. POOOOl does not contain any requirement that the re-submitted
    first article be newly manufactured.
    21. On 25 July 2013 MAP submitted a Request for Deviation/Waiver 10
    requesting permission to submit a new first article using one of the parts previously
    made. MAP reiterated that the remaining parts had been inspected with pin gauges in
    DCMA's presence and found to be 100% compliant with the .190-.194" hole
    requirement. (R4, tab 19 at 1, tab 20 at 2)
    22. On 29 July 2013, Mr. Raymond Thomas, who had replaced Mr. Fritz as the
    QAR assigned to MAP, responded requesting an "inspection record showing the exact
    dimensions of all the holes for the twelve parts that were made with this first article"
    (R4, tab 20 at 2). Mr. Marin sent an email to Mr. Valenzuela, asking "Can you supply
    this?" (R4, tab 41 at 1). Mr. Valenzuela then sent Mr. Marin a copy of the inspection
    he had performed of the first article back in November 2011 (id. at 1, 10). Mr. Marin
    responded, "We need a QD form for the 12 extra parts ... not the 1 part we sent...can
    10
    MAP asserts that it was directed by DCMA to file a waiver request as an alternative
    to manufacturing more parts (app. reply br. at 6). However, there is no
    evidence in the record supporting this assertion.
    11
    you help?" Mr. Valenzuela responded, "I can modify or create a new one because the
    rest of the parts was finished, same machine and same program." (R4, tab 42 at 1) 11
    23. Subsequently Mr. Marin sent Mr. Thomas an email with the message "See
    attached" (R4, tab 45). It is unclear from the Rule 4 file what was actually attached to his
    email. In any event, Mr. Thomas replied:
    Rob,
    Thank you for providing the inspection record from your
    sampling. However I will need an inspection record for
    each individual part that was made with the failed first
    article showing the actual measurements for each hole that
    is covered by .190-.194 DIA tolerance. Failure to provide
    the documentation by 1 Aug. will cause the waiver to be
    processed without this information.
    (R4, tab 20 at 1)
    24. Mr. Marin then emailed Mr. Valenzuela, commenting "This seems
    unreasonable .. .! think measurements of 144 holes is excessive and unnecessary. Any
    thoughts?" (R4, tab 111 at 8)
    25. Mr. Thomas and Mr. Keeler visited MAP on 1August2013. Mr. Valenzuela
    declares that:
    I am sure I presented one new good part from inventory,
    sometime after the first article rejection, to DCMA QAR
    Greg Keeler. He said something to the effect of, "I'm
    good with that. All you need is a mod now." I believe this
    was on August Pt, 2013 to the best of my memory.
    (R4, tab 110,, 8) Mr. Marin states:
    I am unsure about the events that occurred when DCMA
    was at MAP's facility on 1August2013 for our regular
    weekly QAR witness of parts, which is the deadline
    QAR Thomas gave MAP to show inspection records
    ofr [sic] all the holes for parts in inventory. However, the
    11
    While the dates on these emails are considered reliable, the times are not. Most of
    the emails are printed from government counsel's computer and it appears the
    computer may have converted the original times of the most recent email in
    each series from Pacific Time to Eastern Standard Time.
    12
    attached email from me [referring to his 29 July 2013
    email quoted above] shows we knew inspection of all 144
    holes in the good parts we had in stock could damage the
    .190/.194 holes and may be the reason we failed to perform
    the inspection. I believe this would be an issue we would
    likely address with DCMA on that date, but we have no
    other record of what transpired.
    (R4, tab 111, ~ 10)
    26. Mr. Thomas's recollection of the I August meeting is as follows:
    On August 1, 2013, I was at the MAP facility for a weekly
    meeting. I asked Mr. Marin if MAP had an inspection
    record showing dimensional measurements of all the holes
    in all of the parts and he said he did not.
    (Gov't br., ex. E, Thomas decl.   ~   4) The record does not include a declaration from
    Mr. Keeler.
    27. On 5 August 2013, DCMA's Mr. Presley forwarded MAP's waiver request
    package to DLA's Mr. Skimin for final approval/disapproval action by DLA Aviation.
    In the forwarding email, Mr. Presley stated: "Please note our functional specialists
    have reviewed this waiver request and do not recommend approval." (R4, tab 21 at I)
    By email dated 20 December 2013 (the delay is unexplained in the record), DLA
    notified MAP that its waiver request had been denied (R4, tab 22). Attached to the
    email were DCMA's comments on Form DD 1998. Mr. Thomas had commented, "I
    am not aware of any DCMA 100% inspection of the remaining twelve remaining [sic]
    parts. Requested the contractor provide inspection records for [sic] show the I 00% ·
    compliance with the .194/.190 requirement. The contractor never provided the
    records." (R4, tab 22 at 5) There is no explanation in the record of why Mr. Thomas
    insisted on an exact measurement of each hole in all the parts, vs. a pass/fail inspection.
    28. In a 20 December 2013 email, Mr. Skimin ofDLA's contracting office
    informed MAP that:
    Your RFW/RFD, dated 7/24/2013, has been denied. The
    First article exhibit did not conform to Technical Data
    Package requirements. Initial First Article disposition was
    "Disapproved". Pursuant to FAR 52.209-4(h), before first
    article approval, the acquisition of materials or components
    for, or the commencement of production of, the balance of
    the contract quantity is at the sole risk of the Contractor.
    Your firm has 2 remaining options: I-resubmit a
    13
    conforming first article for government evaluation, as
    prescribed in Modification POOO[O]l dated 2 MAY 2013;
    or 2-take no action."
    A response was requested by 27 December 2013. (R4, tab 22 at 1)
    29. On 27 December 2013, MAP (Mr. Marin) responded in part:
    We respectfully reiterate our original position that the first
    article for this contract was erroneously rejected by the
    Government and the production parts we currently have in
    our possession, sufficient in quantity to satisfy the
    requirements of the entire contract, should be inspected
    and accepted. Delivery of production parts would occur
    when the final inspection paperwork is completed by
    MAP, within two weeks of Government notification of
    acceptance of this proposal.
    We also respectfully decline to manufacture a new lot of
    first article parts.
    (R4, tab 23 at 1) Mr. Marin further articulated the view that since the nonconforming holes
    and the holes from which paint had been removed were the same holes, the observed
    discrepancy was easily correctable in production and the government should have
    conditionally approved the part. He stated that the government had failed to explain its
    basis for refusing to allow other parts manufactured at the same time to be used for a new
    first article submission and, while he assumed that the government was relying on the
    contract clause stating that "any defective item discovered during inspection may be cause
    for rejection of the entire contract quantity," he did not believe that clause applied to the
    current situation but to instances where latent defects may be present in production parts or
    fraud or misrepresentation had occurred. (Id. at 1-2)
    30. The record does not indicate whether the CO responded to Mr. Marin's email,
    other than to withdraw the purchase order for failure to meet the first article delivery date
    by unilateral Mod. P00002, effective 13 January 2014 (R4, tab 3). On 21April2015,
    MAP submitted its claim for breach of contract, alleging breach of the implied duty of
    good faith and fair dealing and seeking as damages restitution of the cost incurred to
    manufacture the parts ($10,591.42) plus the $651.07 paid to DLA as consideration for
    Mod. POOOO 1 (R4, tab 25). The claim was denied by CO Hicks on 13 May 2015 (R4,
    tab 26), and this appeal followed.
    31. MAP' s inspection of the first article as well as other parts in the same
    production run before the first article was shipped to the government for first article
    testing consistently recorded conforming hole diameters ranging from .191 to .194
    14
    inches (finding 11). Government QAR Gordon Gregory signed off on MAP's first
    article test report on 30 January 2012 expressly noting that he had witnessed the
    dimensional inspection and methods and recommending FAT approval (id.). The
    contract required that cadmium plating and epoxy-polyamide primer be applied to the
    part as part of the manufacturing process prior to shipment and testing of the first
    article (finding 1). The first article and all the other parts manufactured in the same
    production run therefore had both cadmium plating and primer applied prior to
    shipment of the first article to the government for testing.
    32. After inspection, the government's dimensional technician reported that
    instead of the required dimension of .190 to .194 inches, the diameter of the holes was
    .195 to .196 inches "[in] twelve places." This was the only respect in which the first
    article did not meet contract requirements. (Finding 3) When the disapproved first
    article part was returned to MAP for inspection in the presence of the DCMA QARs
    on 20 June 2012, only three holes out of the total of twelve holes were found to be
    .195 to .196 inches in diameter, while the remaining nine were the required .190 to
    .194 inches in diameter (finding 5). The three nonconforming holes all had paint
    missing (id.). The nine holes that did not have paint missing were measured as
    conforming (id.).
    33. The government does not dispute either that the nine holes without paint
    removed were conforming, or that all three nonconforming holes had paint missing.
    When Mr. Marin of MAP observed following the 20 June 2012 inspection of the
    returned part that the nonconforming condition could have been caused during the
    government inspection by forcing a gauge pin through the holes, thereby removing the
    paint, government QAR Fritz found this theory plausible, but unlikely (finding 5). The
    government's dimensional technician, on the other hand, while denying that she forced
    a gauge pin through the holes, stated that it is possible paint was removed during the
    inspection process and that the removal of paint would be a "typical" result of the
    inspection process (finding 7).
    34. Based on the ESA technician's use of pin gauges during the inspection
    process (finding 8), her admission that paint could have been removed during her
    inspection and that such a result would be "typical," the evidence of record that pin
    gauges are not suitable for exact hole measurement because they tend to enlarge the
    hole (finding 15), the fact that a dimensional discrepancy of only two thousandths of
    an inch ( .196 vs .. 194) separated the failing holes from the passing holes, and the fact
    that paint was missing from the failing holes and only from the failing holes, we find
    that it most probable that the technician attempted an exact measurement of three holes
    with gauge pins, removing paint in the process, and then extrapolated the results to the
    other holes. Based on the evidence that the holes met the required dimensions prior to
    being shipped to the government for testing (finding 11) and no other discrepancies
    were noted in the inspection process (finding 3), we further find that MAP's first
    article met all contract requirements and that the dimensional discrepancy that resulted
    15
    in the disapproval ofMAP's first article was caused by the government's own
    inspection process. 12
    35. The contract in this case was a unilateral purchase order which by its terms
    lapses if complete performance in accordance with the offer's terms and conditions is
    not tendered. We find that MAP first tendered performance that met the offer's terms
    and conditions on 30 January 2012, when it shipped its first article for government
    inspection (finding 3). Thus, the unilateral purchase order was converted to a contract
    as of that date.
    36. In finding that the first article met the contract requirements, we necessarily
    reject the government's argument that the 12 holes in MAP's first article part were
    required to meet the specified dimensions after paint was removed. The government
    has not directed us to any contract provision supporting this argument, and we have
    found none. To the contrary, the contract required that a cadmium coating and primer
    both be applied to the part before shipping it for inspection (finding 1), and thus we
    find that the contract required the dimensional requirement to be met with paint, not
    without.
    37. Because MAP's first article met all contract requirements when shipped to
    the government (finding 34), we find that the CO's disapproval of that first article was
    improper. We also find that the CO's subsequent failure to acknowledge (1) that the
    government's own inspection process removed paint from three holes in MAP's part,
    causing them to be out of tolerance, and (2) that the remaining parts in MAP's
    inventory were in tolerance and acceptable, was unreasonable based in part on
    information known to her and in part on information known to the DCMA QARs
    whose knowledge is imputed to her. The QARs knew or had reason to know, either
    from the initial inspection of the first article part (findings 11, 31 ), or from the
    subsequent inspections of the disapproved first article compared to other parts
    manufactured at the same time (findings 5, 32), that the first article was damaged
    while in the government's possession and that the parts from the same run that MAP
    had in stock were fully acceptable under the contract. 13 The CO herself was personally
    12
    With respect to our finding that MAP's first article met the contract requirements,
    we note that the government has introduced evidence of difficulties MAP
    encountered at the outset in manufacturing this part. MAP has explained in a
    supplemental declaration from Mr. Marin that its first attempt at production
    employed two inexperienced machinists due to a labor shortage (app. reply br.,
    ex. F ,-i 8). The second production run from which the first article was
    submitted employed two experienced machinists and no notable problems were
    encountered (id.). The government has not introduced any evidence that MAP
    experienced any difficulties in manufacturing the first article that was actually
    submitted.
    13
    The record does not reveal whether or not this information was actually shared with her.
    16
    aware from MAP's contract correspondence that MAP contended its first article had
    been damaged by the government and that its remaining parts were acceptable, yet
    rejected MAP's offer to deliver the parts and let the government see for itself
    (findings 16-17).
    38. Once MAP executed Mod. POOOOl establishing a new first article delivery
    date, it submitted a request for waiver/deviation again seeking the government's
    concurrence that it could submit an existing part as its first article. Raymond Thomas,
    the then-QAR, responded requesting an inspection record "showing the exact
    dimensions of all the holes for the twelve parts that were made with this first article."
    (Findings 21, 22) QAR Thomas provided no explanation to MAP of why exact
    measurement of the diameter of each hole in each part was needed to determine the
    dimensional compliance of the holes, and none otherwise appears in the record
    (finding 27). From the evidence of record (findings 7, 17), the Board concludes that
    pass/fail inspection using go/no-go gauges would have provided the government with
    adequate assurance that the holes were compliant, and, moreover, that exact
    measurement posed a risk of enlarging the holes and destroying what otherwise would
    have been a good part, as happened in the initial government inspection. Thus, we
    find the QAR's insistence on exact measurement of each of 144 holes to have been
    unreasonable, and the CO's denial of MAP's waiver request based on its failure to
    conduct an exact measurement of 144 holes to also have been unreasonable.
    39. The CO's failure to acknowledge that government-caused damage to
    MAP's first article was the sole cause of its disapproval led directly and inevitably to
    her subsequent actions we find to have been unreasonable: the CO's failure to allow
    MAP a no-cost resubmittal (findings 16-17); the CO's imposition of a requirement that
    MAP manufacture a new part for the re-submittal (findings 18-19); the CO's denial of
    MAP's waiver request based on MAP's failure to comply with DCMA's unreasonable
    requirement to measure all 144 holes (findings 22, 27); and, ultimately, the CO's
    unilateral cancellation of the contract in January 2014 (finding 30).
    DISCUSSION
    MAP asserts that the government was not justified in disapproving its first
    article part because the government's unduly forceful inspection damaged the three
    holes found to be nonconforming. MAP also asserts that by insisting that the hole
    dimensions without paint meet the specified dimensions, the government imposed a
    more stringent or different inspection standard in its inspection of MAP's first article
    than provided for in the contract. In their totality, MAP asserts, the government's
    actions in this case violated the implied duty of good faith and fair dealing and
    constituted a breach of contract. MAP asserts entitlement to restitution, to restore it to
    the status quo ante (as if there never had been a contract that was breached), in the
    amount of $11,242.49. (R4, tab 25; app. br. at 9-16)
    17
    The government asserts at the outset that the unilateral purchase order at issue in this
    appeal, as modified by bilateral Mod. POOOO 1, required delivery of a first article by
    24 October 2013, and since MAP failed to do so, the CO was justified in cancelling the
    order (gov't br. at 24-25). The government acknowledges that MAP's position is that the
    CO abused her discretion in not allowing MAP to resubmit a first article using one of the
    production parts it had already manufactured (id. at 25). The government's response to this
    is in two parts: first, the government argues that MAP agreed to submit a newly
    manufactured first article by entering into Mod. POOOO 1 after being informed by
    government representatives that only a newly manufactured first article would be acceptable
    (id. at 25-26). Secondly, the government argues that, aside from Mod. POOOOl, the contract
    clause specifically stating that any defective item discovered during inspection may be
    cause for rejection of the entire contract quantity gave the CO the right to decide not to
    accept any parts made in the same production run as the disapproved first article (id. at 26).
    As to the issue whether the government was justified in disapproving the initial
    first article, the government first argues that MAP is foreclosed from contesting this
    issue by having entered into Mod. POOOO 1, citing James Electronics, Inc., 
    ASBCA No. 43505
    , 93-2 BCA ~ 25,677 at 127,728 (by agreeing to a new delivery schedule
    after two failed first article submissions, appellant surrendered its right to argue any
    then existing causes as a defense to its failure to deliver an acceptable first article on
    the third submittal) (id. at 30-31). Secondly, the government states that the
    disapproval, if reviewable, was correct because the holes in the part were oversized
    and MAP has not met its burden of proving that this defect was easily correctable in
    production (id. at 32-33).
    To recover on its breach of contract theory, MAP must show ( 1) a valid contract
    between the parties; (2) an obligation or duty of the government arising out of the
    contract, (3) a breach of that duty, and (4) damages caused by the breach. San Carlos
    Irrigation & Drainage Dist. v. United States, 
    877 F.2d 957
    , 959 (Fed. Cir. 1989);
    Northrop Grumman Systems Corporation Space Systems Division, 
    ASBCA No. 54774
    ,
    10-2 BCA ~ 34,517 at 170,23 7. We consider each of these elements in tum.
    1. A valid contract between the parties. The contract in this case was a
    unilateral purchase order. As such, as a matter of law, it constitutes an offer to buy
    certain supplies on specified terms and conditions if the offer is accepted by delivering
    those supplies on or before the date specified. If complete performance in accordance
    with the offer's terms and conditions is not tendered, the offer lapses by its terms.
    Comptech Corp., 
    ASBCA No. 55526
    , 08-2 BCA ~ 33,982 at 168,082. We have found
    that MAP did tender acceptable performance (finding 35). Therefore, Order
    No. SPM4A7-l l-M-Dl 11 was a valid contract between the parties.
    2. An obligation or duty of the government arising out of the contract. The
    government was obligated to evaluate MAP's first article in a reasonable manner in
    accordance with the terms of the contract. First articles are typically not production items
    18
    and, unlike production items, which are either accepted or rejected, first articles are either
    approved, conditionally approved, or disapproved. Military Aircraft Parts, 
    ASBCA No. 59978
    , 15-1BCA~36,101at176,258; see also FAR 52.209-4, FIRST ARTICLE
    APPROVAL - GOVERNMENT TESTING (SEP 1989) clause, which was included in the
    contract (finding 2): "Within 120 calendar days after the Government receives the first
    article, the Contracting Officer shall notify the Contractor, in writing, of the conditional
    approval, approval, or disapproval of the first article" (id. ~ (b) ). This clause is
    prescribed for use in contracts by FAR Part 9, Contractor Qualifications, which in
    Subpart 9.3, First Article Testing and Approval, sets forth the purpose of first article
    testing, which is to ensure that a contractor "can furnish a product that conforms to all
    contract requirements for acceptance." FAR 9.302.
    The first article clause does not give the government the right to disapprove a
    first article for any noncompliance with specifications that would be a valid reason for
    rejection of supplies tendered for delivery under the contract. Marvin Engineering
    Co., 
    ASBCA No. 27016
    , 84-2 BCA ~ 17,401 at 86,674. Ordinarily, the primary
    purpose for requiring first article submission is to prove the capability of the contractor
    to produce end products that will meet contract requirements. 
    Id.
     (citing Astra Science
    Corp. v. United States, 471F.2d624 (Ct. Cl. 1973); Farris and Company, 
    ASBCA No. 31275
    , 73-1 BCA ~ 9963)). Deficiencies in a first article that are correctable in
    production are not a valid basis for an outright disapproval and, in recognition of this,
    the first article approval clause expressly provides for conditional approval. 
    Id.
    First article testing and inspection of supplies have distinctly different purposes.
    As noted above, the purpose of first article testing is to determine whether the
    contractor can produce the supplies to the contract specifications. FAR 9.302. FAR
    Part 9 governs contractor qualifications and prescribes the use of the first article
    testing clause, FAR 52.209-4, under which deficiencies in a first article that are
    correctible in production are not grounds for disapproval. The purpose of inspection
    of supplies, on the other hand, is to determine whether production parts that have been
    delivered should be accepted. FAR Part 46, Quality Assurance, governs the inspection
    of delivered supplies and services.
    In addition, both parties to the contract owe each other the implied duty of good
    faith and fair dealing. In Metcalf Construction Co. v. United States, 
    742 F.3d 984
    , 990
    (Fed. Cir. 2014), the United States Court of Appeals for the Federal Circuit affirmed
    the basic principle that the parties to a government contract are under a duty of good
    faith and fair dealing in the performance and enforcement of the contract, and that
    failure to fulfill that duty constitutes a breach. "The covenant of good faith and fair
    dealing .. .imposes obligations on both contracting parties that include the duty not to
    interfere with the other party's performance and not to act so as to destroy the
    reasonable expectations of the other party regarding thefruits of the contract." 
    Id.
     at
    991 (citing Centex Corp. v. United States, 
    395 F.3d 1283
    , 1304 (Fed. Cir. 2005)).
    19
    In order to prove a violation of the duty, a contractor need not necessarily prove
    that the government specifically targeted action to obtain the benefit of the contract or
    that the government's actions were undertaken for the purpose of delaying or
    hampering performance of the contract. Metcalf, 742 F.3d at 993. Rather, the implied
    duty of good faith and fair dealing is "limited by the original bargain: it prevents a
    party's acts or omissions that, though not proscribed by the contract expressly, are
    inconsistent with the contract's purpose and deprive the other party of the
    contemplated value." Id. at 991.
    3. A breach of the duty. Based on the record before us, we have found that
    MAP's first article met all contract requirements, including hole diameter, when shipped
    to the government. Were it not for the damage caused to the first article while in the
    government's possession, there would not have existed any reason not to approve the
    first article. Thus, the CO's disapproval of the first article submitted by MAP on
    30 January 2012 was unreasonable. In addition, the CO's refusal to allow MAP to
    submit another part from the same production run for re-testing, the after-the-fact
    imposition of a requirement that the holes in the part meet the dimensional requirement
    without paint, and the insistence that MAP conduct exact measurements of all 144 holes
    before a waiver would be considered, had no basis in the contract and were unreasonable.
    (Findings 37-39)
    These acts were in violation both of the government's duty to evaluate MAP's
    first article in accordance with the express terms of the contract, and its implied duty to
    cooperate and not willfully or negligently hinder the contractor's performance.
    American Ordnance LLC, 
    ASBCA No. 54718
    , 10-1BCA~34,386 at 169,795 (citing
    Malone v. United States, 
    849 F.2d 1441
    , 1445 (Fed. Cir. 1988)). We impute to the CO
    the knowledge of her representatives, the DCMA QARs, in finding the government's
    conduct to have been a breach of the duty of good faith and fair dealing. Walter Straga,
    
    ASBCA No. 26134
    , 83-2 BCA ~ 16,611at82,617-18.
    We find inapposite the government's argument that our holding in James
    Electronics forecloses MAP from contesting the CO's disapproval of the first article.
    In that case, we held that the government had met its burden to show that the
    submitted first article, on a third submission, failed to meet contract requirements, and
    that the contractor had not met its burden to show that the defects were easily
    correctable in production. 93-2 BCA ~ 25,677 at 127,728. In connection with the
    latter holding, we observed:
    To the extent that appellant's brief concentrates
    upon initial problems in appellant's obtaining copies of
    pertinent specifications and differences in test
    configuration when the second FA submittal was rejected,
    as excusable causes for default, it is unavailing. The law is
    clear that by agreeing to a new delivery schedule, which
    20
    appellant did in the fall of 1990, long after the first two FA
    rejections .. .it surrendered its right to argue any then
    existing causes as a defense to its failure to deliver an
    acceptable FA on its third submittal.
    
    Id.
     In stark contrast, in this case MAP contends, and the preponderance of the
    evidence shows, that MAP's first article did meet contract requirements when first
    submitted. MAP is not presenting "defenses" to a failure to deliver an acceptable first
    article because there was no such failure.
    We also reject the government's contention that CO Hicks was justified in
    requiring a newly manufactured first article because the contract included a clause
    stating that any defective item discovered during inspection may be cause for rejection
    of the entire contract quantity (gov't br. at 26). This clause, reproduced in full at
    finding 18, refers to "SAMPLING FOR INSPECTION AND TESTING," and states
    that "ANY DEFECTIVE ITEM DISCOVERED DURING INSPECTION MAY BE
    CAUSE FOR REJECTION OF THE ENTIRE CONTRACT QUANTITY." This
    language contemplates that a production lot will be delivered and items (the sample)
    will be selected from that lot for testing that will result in acceptance or possibly
    rejection of the entire lot. In contrast, the contract's first article testing clause, which
    applies in this case, calls for the delivery of an item or items that are not expected to be
    part of a production lot and which are inspected for the purpose of determining
    whether the contractor has the capability of producing items that meet the contract
    requirements. If the first article is approved or conditionally approved, then the
    contractor is given the opportunity to deliver the production quantity.
    In order to shed light on the applicability of this clause to first article testing,
    the government was directed to supplement the record in this appeal with more
    information about the provenance of the clause. In response, the government informed
    the Board that the language of the clause is not part of any standard contract clause,
    and that it is included in Section B of the contract as part of the "standalone narrative
    terms of the contract" (Bd. corr. file, ltr. dated 9 February 2016). The government also
    provided the Board with an electronic link to the archived version of the DLAD in
    effect at the time the contract was issued (representing that the full DLAD comprised
    approximately 750 pages). The government stated further:
    With respect to the Board's question about whether
    the clause applies to first article testing or production lot
    testing, Respondent's position is that the plain terms of the
    clause state that it applies to inspection ("Any defective
    item discovered during inspection ... ") and there are two
    inspection points identified in the contract - the first article
    inspection and the production quantity inspection. Se[ e]
    R4 Tab 1 at 2 ("F AT:Inspection=Origin, Acceptance=
    21
    Destination; Remaining Production:
    Inspection/Acceptance=Origin). Respondent further notes
    that the contract does not contemplate production lot
    testing as there is no Production Lot Test clause in the
    contract. See DLAD 52.209-9026, Production lot test
    (PLT)
    (http://farsite.hill.af.mil/archive/Dlad/Rev5_PROCL TRI 0-
    40/Part52.htm).
    (Bd. corr. ltr. dtd. 22 February 2016)
    The Board agrees that the contract does not contain the cited production lot
    testing clause. This makes sense, since the contract calls for first article testing, not
    production lot testing. The contract's first article testing clause, FAR 52.209-4, provides
    that following first article disapproval, if the government requests it, the contractor shall
    submit an additional first article for approval (finding 2). Nothing in the first article
    clause gives the government the right to dictate that only a newly manufactured part may
    be submitted as the additional first article. Nor does the non-standard contract language
    on which the government relies, as explained below.
    The Board's review of the archived DLAD revealed that, subsequent to the issuance
    of the subject contract, pursuant to PROCLTR 11-45, PRODUCTION LOT TEST (PL T) (JAN
    2009) clause, DLAD 52.209-9026, was removed and replaced with new clauses:
    DLAD 52.246-9085, PRODUCTION LOT TESTING (PL T) - GOVERNMENT (JUL 2011 ); and
    DLAD 52.246-9086, PRODUCTION LOT TESTING (PL T) - CONTRACTOR (JUL 2011 ),
    Furthermore, the production lot testing clause (JUL 2011) contains language very similar to
    that on which the government relies:
    (e) Upon completion of the PL T sample testing, the
    Government test facility will provide the results to the
    FAT/Testing Monitor (or ACO) and to the Contracting
    Officer. If the PLT sample is disapproved, the
    Government shall advise the Contractor of the
    nonconformance, and whether the Contractor will be
    allowed to produce a new lot to tender for testing.
    Disapproval of the PLT sample is grounds for rejection of
    the entire production lot produced. The Contractor shall
    discard any failed production lot produced and produce a
    new production lot under the contract terms and
    conditions. [Emphasis added]
    22
    http://farsite.hill.af.mil/archive/Dlad/Rev5 _PROCL TRl 1-45/PART52.htm. The
    quoted language is essentially unchanged in the current version of the production lot
    testing clause. 14
    As discussed above, the non-standard contract clause relied on by the
    government, on its face, appears inapplicable to the first article testing process
    contemplated in the contract's first article clause. This, combined with the fact that
    substantially the same provision was incorporated in the 2011 production lot testing
    clause, leads the Board to conclude that the non-standard clause incorporated in the
    contract does not apply to first article testing and may not be invoked by the government
    to justify its imposition on MAP of requirements not authorized in the contract's first
    article testing clause. Moreover, even if we found that the clause properly applied to
    first article testing, it speaks in permissive, not mandatory terms. Under the facts and
    circumstances present in this case-where the part was damaged while in the
    government's possession and there was, therefore, no rational basis for concluding that
    the remaining parts manufactured by MAP were defective-it would still be
    unreasonable and an abuse of discretion for the government to require MAP to
    manufacture a new run of parts for a first article re-submission. In conclusion, the CO's
    insistence that MAP incur the expense of a whole new production run in order for the
    government to conduct another first article test was an unreasonable imposition of yet
    another obstacle to contract performance and a breach of the government's implied duty
    to cooperate and not hinder performance of the contract. 15
    Ultimately, CO Hicks cancelled the purchase order after MAP insisted on its
    right under the contract to submit an existing part for the first article re-testing
    (finding 30). This action was also a breach of the contract, since MAP had effected
    delivery according to the terms of the contract by tendering a conforming first article.
    14
    The Board also finds it significant that both the production lot testing regulatory
    provisions and the related contract clauses were moved from Part 9 of the
    DLAD, which addresses Contractor Qualifications, to Part 46, which addresses
    Quality Assurance. This underscores the distinction in process and purpose
    between first article testing to qualify a contractor to produce a part, and
    inspection of delivered supplies to determine their acceptability.
    15
    We also reject the government's argument that MAP nevertheless agreed to provide
    a newly manufactured first article by entering into Mod. POOOO 1 after being
    informed by a government representative that a newly manufactured first article
    would be required (gov't br. at 25-26). Mod. POOOO 1 on its face did not require
    MAP to submit a newly manufactured first article, and MAP did not otherwise
    acquiesce to the government's demand. The government has not met its burden
    of proof on this issue. DTC Engineers & Constructors, LLC, 
    ASBCA No. 57614
    , 12-1 BCA ~ 34,967 at 171,899.
    23
    While we find numerous breaches, both of express contract duties and the
    implied duty of good faith and fair dealing, we do not find that any of the government
    officials involved acted with malice or specific intent to injure MAP.
    4. Damages caused by the breach. The contract's First Article Testing clause
    provides that the contractor assumes the risk of any production parts manufactured
    prior to first article approval; the cost thereof shall not be allocable to the contract for
    purposes of progress payments or termination settlements (finding 2). In this case,
    neither progress payments nor a constructive termination for convenience are
    presented. Because the contract did not contain the standard Default clause,
    FAR 52 .249-8, even if we were to conclude that the CO' s cancellation of the contract
    equated to an improper termination for default, the government cannot avail itself of
    the conversion of an improper default termination to a termination for convenience
    provided for by paragraph (g) of that clause. 16 This being so, paragraph (h) of the First
    Article Testing clause is not applicable and MAP is entitled to breach damages.
    The contract price of $7550.00 included 1 first article and 6 production parts.
    MAP elected to make 13 parts altogether in one production run, and claims its costs of
    manufacturing all 13 parts ($10,591.42) plus $651.07 paid to DLA as consideration for
    Mod. POOOO 1 (R4, tab 25). We have found that the government breached the contract
    and its actions prevented MAP from successfully delivering conforming parts. Thus,.
    the appropriate measure of foreseeable damages flowing from the government's
    breach is the contract price, $7,550.00.
    We do not grant MAP the full amount of its requested damages. The contract
    only called for six production parts and it would be sheer speculation that it would
    have ordered six more. As to the amount of $651.07 MAP agreed to as consideration
    for the government's agreement to a first article resubmission, MAP has not met its
    burden to show this amount was ever paid to or collected by the govemment. 17
    Accordingly, this appeal is sustained in part.
    16
    Because the Default clause was not required to be included (see fn. 9 above), it is not
    incorporated into the contract by operation of law. American Water Cooling
    Equipment Corp., GSBCA No. 9083-TD, 89-1BCA~21,364 at 107,689; compare
    Turnco Machine Co., 
    ASBCA No. 33559
    , 88-2 BCA ~ 20,551(FAR52.249-8
    required and incorporated by operation of law).
    17
    The government contends this amount was never charged to MAP (gov't br. at 34).
    MAP counters that this amount was deducted from other amounts due and
    owing to MAP per the terms of Mod. POOOO 1. Mod. POOOO 1 states that "the
    payment office will offset the amount of this modification against any
    outstanding payments due, potentially including other contracts" (R4, tab 2
    at 2). We cannot find any evidence in the record that the amount was actually
    collected from MAP.
    24
    I
    CONCLUSION
    For the foregoing reasons, we sustain the appeal in the amount of $7,550.00,
    plus interest pursuant to 41U.S.C.§7109 calculated from 21April2015 until paid.
    Dated: 31 May 2016
    LYNDiO'SULLIVAN
    -
    Administrative Judge
    Armed Services Board
    of Contract Appeals
    I concur
    ~
    ~~~~                                           _Rl_C_H_ARD
    _ _S_H_A_C_K-LE_F_O_RD
    _ _ __
    Administrative Judge                            Administrative Judge
    Acting Chairman                                 Vice Chairman
    Armed Services Board                            Armed Services Board
    of Contract Appeals                             of Contract Appeals
    I certify that the foregoing is a true copy of the Opinion and Decision of the
    Armed Services Board of Contract Appeals in 
    ASBCA No. 60009
    , Appeal of Military
    Aircraft Parts, rendered in conformance with the Board's Charter.
    Dated:
    JEFFREY D. GARDIN
    Recorder, Armed Services
    Board of Contract Appeals
    25
    1
    I