Hale v. Big H Construction , 288 P.3d 1046 ( 2012 )

IN THE UTAH COURT OF APPEALS
‐‐‐‐ooOoo‐‐‐‐
Charles F. Hale and Beverly I. Hale, ) OPINION
)
Plaintiffs and Appellants, ) Case No. 20100785‐CA
)
v. )
) FILED
Big H Construction, Inc., and T. Dwayne ) (October 12, 2012)
Horsley, )
) 2012 UT App 283Defendants and Appellees. )
‐‐‐‐‐
Third District, Salt Lake Department, 050905279
The Honorable Sandra N. Peuler
Attorneys: Kathleen E. McDonald and Vincent C. Rampton, Salt Lake City, for
Appellants
John T. Anderson, Salt Lake City, for Appellees
‐‐‐‐‐
Before Judges Thorne, Voros, and Roth.
VOROS, Judge:
¶1 This case involves a dispute over a cost‐plus contract to build two high‐end
custom homes on adjacent lots. When the builder, Big H Construction, Inc., filed a
mechanics’ lien on one of the homes, the owners, Charles F. Hale and Beverly I. Hale,
sued Big H and its president, T. Dwayne Horsley, for breach of contract and related
claims. Big H counterclaimed for nonpayment of a ten percent builder’s fee. After a
bench trial, the trial court awarded Big H $172,100 plus attorney fees and costs. The
Hales moved unsuccessfully for a new trial and to amend the findings pursuant to rules
52(b) and 59 of the Utah Rules of Civil Procedure. The Hales appeal. We affirm.
BACKGROUND1
¶2 In February 2003, the Hales hired Big H to construct two custom homes on
adjacent lots known as Lots 45 and 46. The parties agreed that Big H would construct
the homes on a cost‐plus basis with the Hales covering all reasonable costs (the Costs)
plus a builder’s fee equal to ten percent of the Costs. The project involved forty‐seven
separate subcontractors and suppliers, some of whom the Hales contracted with and
paid directly over the course of construction.
¶3 Two of Dwayne Horsley’s family members worked on the project in some
capacity with Big H or the Hales or both. David Horsley, Dwayne’s father and a
licensed real estate agent, prepared Real Estate Purchase Contracts (REPCs) for the
Hales’ purchase of the Lots from the developer and their purchase of the homes from
Big H. James Horsley, Dwayne’s brother, negotiated the purchase of Lots 45 and 46 on
the Hales’ behalf and worked as a site foreman.
¶4 The Hales executed an REPC for the purchase of Lots 45 and 46 from Triple
Crown Estates on February 25, 2003. The REPC provided for a three percent
commission to the developer’s agent. David Horsley was listed as the Hales’ agent, but
the REPC did not provide for a commission to him. That same day, the Hales executed
two separate REPCs for the Lot 45 and Lot 46 homes, with Big H listed as seller. The
REPCs listed no agents for either buyers (the Hales) or sellers (Big H) and mentioned no
sales commissions.
¶5 By late 2004, Big H had largely completed construction on the Lot 45 home.
However, the parties’ working relationship had deteriorated. When the Hales refused to
pay anything further, Big H left the project. Approximately three months later, Big H
filed a mechanics’ lien on the Lot 45 home in the amount of $165,000. Big H claimed this
1. “On appeal from a bench trial, we view the evidence in a light most favorable to the
trial court’s findings, and therefore recite the facts consistent with that standard.”
ProMax Dev. Corp. v. Mattson, 943 P.2d 247, 250 n.1 (Utah Ct. App. 1997) (citation and
internal quotation marks omitted). We “present conflicting evidence only to the extent
necessary to understand the issues raised on appeal.” State v. Dunn, 850 P.2d 1201,
1205–06 (Utah 1993).
20100785‐CA 2
sum approximated its builder’s fee. The Hales sued. Big H counterclaimed for breach of
contract and foreclosure of its mechanics’ lien.
¶6 At trial, Big H offered into evidence voluminous documentation, including
stacks of invoices from dozens of vendors documenting expenses and copies of
cancelled checks from the Hales documenting payments. The invoices for both homes
totaled more than $2.7 million. Dwayne Horsley testified about the Costs and payments
that he tracked on a spreadsheet over the course of the project; Big H’s expert witness
testified that the Costs were reasonable. By Big H’s account, the Hales owed it roughly
$172,000 (although that figure varied over the course of the litigation from $165,000 to
$174,000).
¶7 The Hales advanced a different version of Costs incurred and payments made.
They offered testimony from their accounting expert. The Hales’ expert testified that he
had reviewed all the records furnished by the Hales and Big H, and that the Hales had
overpaid Big H by $116,994.77. His conclusion was based in part on “unsupported
costs” and various alleged overpayments and underpayments. However, the trial court
found much of the Hales’ evidence—including their expert’s testimony—unreliable,
and relied instead mainly on the evidence offered by Big H. The trial court found that
Costs of $1,721,000 had been incurred and paid for by the Hales on the Lot 45 home,
entitling Big H to a builder’s fee of $172,100.2
¶8 The trial court entered judgment for Big H in the amount of $172,100 for its
builder’s fee, $94,463 in prejudgment interest, and $342,240.84 in attorney fees and costs.
2. As the Hales point out, the trial court issued a Minute Entry dated February 8, 2010,
that described the basis for the damage award differently. There, the trial court had
concluded that “the costs incurred for the building of both homes [were] reasonable,
and that as a result [Big H was] entitled to a 10% fee in the sum of $274,000 for both
homes,” but that the Hales had paid Big H $100,000 as a fee for the Lot 46 home, leaving
$174,000 owed to Big H. The trial court subsequently reduced that award to $172,100.
The trial court’s Findings of Fact and Conclusions of Law included this figure. We note
also, as the Hales have, that the court’s ruling erroneously states in a separate
paragraph that the Hales owe $162,875. At oral argument, counsel for Big H explained
that this was a clerical error on his part in preparing the document on behalf of the trial
court. The Hales do not dispute that explanation.
20100785‐CA 3
It denied the Hales’ subsequent motion for a new trial or to amend the court’s findings
of fact. The Hales timely appeal.
ISSUES AND STANDARDS OF REVIEW
¶9 First, the Hales contend that the trial court erred in ruling that Big H met its
burden at trial because it relied on estimates rather than an actual accounting of Costs.
“Whether the trial court calculated the damages award within the framework dictated
by the [contract] . . . is a question of law,” Traco Steel Erectors, Inc. v. Comtrol, Inc., 2009
UT 81, ¶ 21, 222 P.3d 1164, which we review for correctness, see State v. Pena, 869 P.2d
932, 936 (Utah 1994), holding modified by State v. Levin, 2006 UT 50, 144 P.3d 1096.
However, “an appeal from the types of properly admitted evidence upon which the
trial court applies” the damages formula is “an appeal from a question of fact,” Traco,
2009 UT 81, ¶ 33. “In all actions tried upon the facts without a jury, . . . [f]indings of
fact . . . shall not be set aside unless clearly erroneous, and due regard shall be given to
the opportunity of the trial court to judge the credibility of the witnesses.” Utah R. Civ.
P. 52(a). A finding is clearly erroneous “‘only if the finding is without adequate
evidentiary support or induced by an erroneous view of the law.’” State v. Walker, 743
P.2d 191, 193 (Utah 1987) (quoting Wright & Miller, Federal Practice & Procedure § 2585
(1971)). Therefore, we will not disturb a finding unless it is “against the clear weight of
the evidence, or if [we] otherwise reach[] a definite and firm conviction that a mistake
has been made.” Id.
¶10 Second, the Hales contend that the trial court included in its calculation other
“improper and unreasonable costs,” including duplicate and mistaken invoices, and
both overpayments and underpayments by Big H. This question involves a finding of
fact that we review for clear error. See Traco, 2009 UT 81, ¶¶ 17, 33.
¶11 Third, the Hales challenge the trial court’s finding that the Hales were not
entitled to an offset based on Big H’s alleged failure to perform work in a good and
workmanlike manner. This challenge presents a mixed question of law and fact. “It is
therefore reviewed under a clearly erroneous standard for questions of fact and a
correctness standard for questions of law.” Tooele Assocs. Ltd. Partnership v. Tooele City
Corp., 2011 UT 04, ¶ 16, 247 P.3d 371.
20100785‐CA 4
¶12 Fourth, the Hales assert that the trial court erred by including the cost of the land
in its calculation of the builder’s fee, arguing that doing so runs afoul of the Utah Real
Estate Licensing and Practices Act, see Utah Code Ann. §§ 61‐2‐1 to ‐24 (Lexis
Publishing 2000) (current version at id. §§ 61‐2f‐101 to ‐512 (LexisNexis 2011 & Supp.
2012)).3 Determining whether inclusion of the cost of the land in calculating Big H’s
builder’s fee violates the statute is a legal question of statutory interpretation that we
review for correctness. See Sachs v. Lesser, 2008 UT 87, ¶ 9, 207 P.3d 1215.
¶13 Fifth, the Hales challenge the finding that they are not entitled to a credit from
Big H for a $30,000 payment the Hales made to James Horsley. This issue turns on
whether James Horsley had authority to act on behalf of Big H, a mixed question of law
and fact. See Glew v. Ohio Sav. Bank, 2007 UT 56, ¶ 19, 181 P.3d 791. We review the
court’s legal conclusions for correction of error, see Tooele Assocs., 2011 UT 04, ¶ 16, but
“[w]e will not disturb the court’s findings of fact unless they are clearly erroneous,”
Glew, 2007 UT 56, ¶ 18. “[I]n those instances in which the trial court’s findings include
inferences drawn from the evidence, we will not take issue with those inferences unless
the logic upon which their extrapolation from the evidence is based is so flawed as to
render the inference clearly erroneous.” Id. Furthermore, because the trial court’s
application of the equitable doctrine of apparent authority is “extremely fact‐sensitive,”
“we grant significant deference” to the trial court. Id. ¶ 19.
¶14 Finally, the Hales challenge the trial court’s conclusion that neither Big H nor
Dwayne Horsley violated the Utah Mechanics’ Lien statute, see Utah Code Ann. § 38‐1‐
25 (LexisNexis 2005). Whether Dwayne Horsley intentionally filed an inflated lien is a
question of fact. Therefore, we review this claim for clear error. See Traco Steel Erectors,
Inc. v. Comtrol, Inc., 2009 UT 81, ¶ 17, 222 P.3d 1164.
ANALYSIS
¶15 We note at the outset that the Hales face an uncomfortable reality on appeal: the
trial court expressly determined that neither Charles Hale nor the Hales’ expert was a
3. Although we cite the version of the statute in effect at the time the litigation was
initiated, we refer to the statute by its current name for ease of reference.
20100785‐CA 5
credible witness. As to Charles Hale’s credibility, the court found that “he has little or
none”:
On the important issue of [Charles] Hale’s credibility, the
Court determines that he has little or none, generally, and on
several key points, specifically. . . . His testimony . . . was not
believable, was inherently implausible, was contradicted by
his own deposition testimony, and/or was contradicted by
other credible witnesses such as . . . [Dwayne] Horsley.
The trial court was equally skeptical of the Hales’ expert. It found that his Analysis and
Report was “riddled with numerous flaws in the way that its figures [were] formatted,
reported and analyzed.” This conclusion left the court with “little or no confidence that
his Analysis and Report is reliable”; consequently, the court “decline[d] generally to
accept any of [the Hales’ expert]’s conclusions.”
¶16 Assessing the credibility of a witness is within the trial court’s domain. See
Rawlings v. Rawlings, 2010 UT 52, ¶ 45, 240 P.3d 754 (“We are keenly aware that trial
courts are in the best position to make determinations about credibility and veracity.”);
Lamkin v. Lynch, 600 P.2d 530, 531 (Utah 1979) (“The matter of witness credibility . . .
falls within the province of the fact‐finder.”). Given the trial court’s credibility
assessment, the Hales face an uphill battle to demonstrate on appeal that the court’s
findings of fact—many of which are based in significant part on witness testimony—are
clearly erroneous.
I. The Trial Court Did Not Improperly Determine Costs.
A. Cost Estimates
¶17 The Hales contend that the trial court erred in ruling that Big H proved its
mechanics’ lien and breach of contract claims because the court “relied on estimates
rather than complete accounting evidence.”
¶18 The trial court considered a compilation of invoices and payment records
submitted by Big H that filled two voluminous three‐ring binders, one of which was
dedicated to documentation of Costs and payments for the Lot 45 home. As Big H
20100785‐CA 6
points out, it “adduced, and the trial court credited, extensive documentary evidence of
every billing invoice and available payment record for every claimed Cost on which
Big H’s ten percent [builder’s fee] was based.” The trial court found that the invoices
and payment records that Big H offered to substantiate its Costs “appear[ed] to be
accurate reflections of the actual Costs for which Big H was billing,” and that “the Hales
ordered, and Big H provided, every material and service reflected in the invoices.”
Moreover, the trial court noted that the incomplete state of payment documentation
was owing, at least in part, to the Hales’ failure to keep Big H apprised of their direct
payments to suppliers and subcontractors over the course of the project. Based on this
evidence, the trial court arrived at its damage award of $172,100 in favor of Big H.4
¶19 In addition to this documentation, Big H introduced expert testimony that the
Costs were reasonable. Big H’s expert relied on two methods of valuation, each based in
some part on estimates. One method relied on the actual invoices for Lot 45, an index of
construction costs produced by R.S. Means, and the expert’s own database of costs. The
other method calculated value on a price‐per‐square‐foot basis and added a fifteen
percent premium to account for high‐quality amenities. Based on his analysis, Big H’s
expert estimated that the value of the Lot 45 home was consistent with the Costs Big H
asserted, and concluded, therefore, that Big H’s Costs were reasonable.
¶20 The Hales challenge this expert testimony. “In a cost‐plus contract,” they
maintain, “the contractor can satisfy its burden of proof only with evidence of actual
expenditures and payments; estimates and averages may not be used.” In support of
their claim, the Hales cite cases from six other states. We need not consider foreign
precedent, however, because the issue was settled by our own supreme court three
years ago in Traco Steel Erectors, Inc. v. Comtrol, Inc., 2009 UT 81, 222 P.3d 1164.
¶21 In Traco, a general contractor hired a subcontractor for steel erection work. Under
their agreement, the general contractor could recover the actual costs incurred along
with reasonable overhead and profits for completing any work that the subcontractor
failed to perform. See id. ¶ 5. When the subcontractor abandoned the job before
completion, the general contractor completed the work using its own labor force along
4. The trial court’s damage award was thus based primarily on Big H’s invoices,
payment documentation, and a spreadsheet Dwayne Horsley used to track Costs—not
on expert estimates.
20100785‐CA 7
with that of another company, then sought to recover its costs from the subcontractor.
See id. ¶ 7.
¶22 To account for its labor costs at trial, the general contractor introduced R.S. Means
Building Construction Cost Data: 2001 Western Edition (Philip R. Waier ed., 14th ed. 2001)
into evidence. This is “an index of average wages and costs for skilled structural
steelworkers and equipment in the western United States” that contains typical billing
rates for labor and the average cost of equipment. Traco, 2009 UT 81, ¶ 8. The general
contractor based its labor costs on the R.S. Means data, and the general contractor’s
president testified that the figure was an accurate representation of the actual costs
incurred. See id. ¶¶ 9–10. The trial court awarded the general contractor damages based
in part on these industry averages. See id. ¶ 11. The subcontractor argued on appeal,
much as the Hales do here, that “the trial court improperly relied on the R.S. Means
average and oral testimony to establish the costs . . . actually incurred to complete [the
subcontractor’s] steel erection work.” Id. ¶ 12.
¶23 Our supreme court rejected this argument. It agreed that the general contractor
“was obligated to prove damages as part of its prima facie case and that the
subcontracts only allowed damages in the amount of costs actually incurred.” Id. ¶ 23.
However, it continued, “We are aware of no authority . . . that restricts evidence that
may be used to prove contract damages to primary documentation of actual cash
outlays to workers or suppliers, or [that indicates] that failure to do so results in a
failure to present a prima facie case of damages.” Id. In determining damages, the court
stated, “‘the desired objective is to evaluate any loss suffered by the most direct,
practical and accurate method that can be employed.’” Id. ¶ 24 (quoting Even Odds, Inc.
v. Nielson, 448 P.2d 709, 711 (Utah 1968)). On appeal, “[t]he central inquiry is whether
the evidence was sufficient; not whether it was perfect.” Id.¶24 Here, Big H produced extensive documentation of actual costs. It used expert
testimony and evidence of industry averages to verify those costs and establish that the
costs were reasonable. The Hales’ challenge to Big H’s use of estimates and averages is
the very attempt rejected in Traco to “restrict[] evidence that may be used to prove
contract damages to primary documentation of actual cash outlays to workers or
suppliers,” id. ¶ 23. Indeed, the Hales criticize the trial court here for relying on an
index similar to that used in Traco. And while the Hales seek to distinguish Traco on the
ground that one of the parties here—the Hales—is a nonbuilder, the supreme court’s
20100785‐CA 8
reasoning in Traco did not rely on the professional status of the parties. The Hales’ claim
is thus squarely foreclosed by Traco.
B. Damage Calculation Formula
¶25 The Hales’ next contention is a variation of their first. They argue that by relying
on expert testimony “based . . . on estimates, rather than an accounting of the costs and
payments,” the trial court employed a “methodology to calculate damages [that] is
fundamentally flawed,” and thus committed an error of law. See Traco Steel Erectors, Inc.
v. Comtrol, Inc., 2009 UT 81, ¶ 21, 222 P.3d 1164 (“Whether the trial court calculated the
damages award within the framework dictated by the [contract] . . . is a question of
law.”).
¶26 The Hales rely on this court’s holding in Wasatch Oil & Gas, LLC v. Reott, 2011 UT
App 152, 263 P.3d 391. The issue addressed in Wasatch Oil was what measure of
damages applied where production from a gas well was interrupted, then restarted
after the price of gas had risen. See id. ¶¶ 10–11. Appellants argued that the trial court
should have applied a lost profits test to determine damages, and this court held that
the trial court had in fact applied such a test. See id. ¶ 11. Neither the nature of the
evidence relied on by the trial court nor the sufficiency of that evidence was at issue in
Wasatch Oil.
¶27 The measure of damages, or the formula by which damages are calculated, is not
at issue here. The parties agree that the contract established a cost‐plus arrangement in
which the Hales would pay Big H Costs plus a builder’s fee equal to ten percent of
those Costs. The trial court explicitly based its damages award on what the trial court
found to be Costs incurred on the Lot 45 home. Specifically, the trial court found that
$1,721,000 of Costs were incurred, entitling Big H to a builder’s fee of $172,100—ten
percent of Costs pursuant to the parties’ contract. The Hales contend not that the trial
court should not have applied a costs‐plus‐ten‐percent measure of damages, but that
Big H’s evidence was insufficient to establish its Costs. Under Traco, Big H’s evidence
was not insufficient merely because Big H used estimates and averages in addition to
documented costs. See Traco, 2009 UT 81, ¶¶ 23–24. Wasatch Oil dictates no different
result.
20100785‐CA 9
II. The Trial Court’s Damage Calculation Is Not Clearly Erroneous.
¶28 Next, the Hales contend that the trial court “permitted improper and
unreasonable costs” in calculating damages, including duplicate and mistaken invoices
and both overpayments and underpayments by Big H to subcontractors or suppliers.
According to the Hales, the trial court “improperly credited Big H twice for duplicate
and mistaken invoices.” These errors, the Hales maintain, are shown in the documents
themselves:
Exhibit D‐RR Item 38 Invoice 4536 and Exhibit SS Item 37
Invoice 4536 for CJ Heating are duplicates, in the amount of
$17,985. In addition, Exhibit SS Item 24 lists Invoice 4601
from Stroud at $120,000, but the invoice is only $60,000. And,
Exhibit SS Item 45 Invoice 1011 is listed twice from RT
Custom Cabinets for $21,000. Accordingly[,] the trial court’s
implied finding that there were not errors or duplicates in
Exhibits RR and SS, and its reliance on those exhibits, is
clearly erroneous.
(Footnotes omitted.)
¶29 Appellants’ brief contains no further explanation or analysis. Yet the identified
exhibits are not self‐explanatory. For example, the C.J. Heating invoice does appear in
apparently duplicate form in both Exhibits RR and SS.5 However, the record does not
clearly show whether this invoice properly belongs only in Exhibit RR (and therefore
was appropriately included in the Lot 45 home Costs calculation), or properly belongs
only in Exhibit SS, or should have been divided between the two, or reflects identical
costs incurred separately for each of the two homes. Yet the Hales offer nothing more
than a bare assertion that the invoices are duplicative. With respect to the Stroud
invoice, the Hales state that “Exhibit SS Item 24 lists Invoice 4601 from Stroud at
$120,000, but the invoice is only $60,000.” However, Invoice 4601 actually shows two
“totals,” one $60,000, the other $120,000. It also shows a payment of $30,000.
5. The C.J. Heating invoice in question appears as invoice number 4536 in both Exhibits
and shows the same date, items, billing rates, and amounts. However, the invoice in
Exhibit RR is marked “Lot 45” while the one in Exhibit SS is marked “Lot 46.”
20100785‐CA 10
Furthermore, as Big H notes, Invoice 1494 from Stroud, dated about six months later,
also shows two “totals,” one $85,954.10, and a “final total” of $59,954.10. The Hales have
not explained these discrepancies or offered record support for their assertion that
$60,000 is the correct total. The RT Custom Cabinet invoices are similarly unclear. The
Hales assert that Invoice 1011 was double‐counted. Big H concedes that the amount on
Invoice 1011 should not have appeared twice on its schedule, but asserts that the
apparent double billing is explained by a different document. The Hales do not address
this additional document, claiming only that Big H is “mistaken.” In short, we cannot
agree with the Hales that these documents on their face prove that the trial court’s
damage calculation was fundamentally flawed and thus clearly erroneous.
¶30 That said, Big H concedes that “the Hales are technically correct that three of the
several hundred billing invoices were not fully accurate,” but notes that “the aggregate
amount of the inaccuracies is $19,294.90 which, when multiplied by 10% [to calculate
the builder’s fee], yields a swing to the Hales of only $1,929.49.” Big H asserts that the
damages award of $172,100 should remain intact despite the errors because “[i]t is more
than offset by the $52,493 of Big H loan advances that the Hales failed to repay.” Indeed,
the trial court found that “[a]ccording to Schedule 8 of [the Hales’ expert]’s twice‐
revised cost and payment analysis, Big H was repaid only $675,205 of the $727,698 that
it advanced to help assure completion of the project.” After trial, the court thus declined
to amend the relevant findings and reduce the damages award because of evidence
showing that the Hales in fact owed Big H substantially more than the $172,100
awarded.
¶31 On appeal, the Hales acknowledge this finding but do not challenge it as clearly
erroneous. Nor do they contend that the trial court was precluded as a matter of law
from backstopping its damage calculation with this unpaid $52,493. And, perhaps more
to the point, the Hales do not challenge Big H’s appellate argument—though not
phrased quite this way—that any errors in the court’s damage calculation that
aggregate less than $52,493 are necessarily harmless. The Hales thus have not
demonstrated that the trial court’s damage calculation requires reversal.
¶32 The Hales also contend that the trial court improperly included overpayments
and underpayments by Big H—that is, payments made to subcontractors and suppliers
for either more or less than the amount reflected in their invoices. The rationale for this
argument is that when the amount actually paid is less than the invoice amount, the
20100785‐CA 11
contractor should base its fee on the former, whereas when the amount paid is more
than the invoice amount, the contractor should base its fee on the latter. Furthermore,
the Hales contend that they “presented undisputed evidence that certain invoices were
underpaid or overpaid. Yet, the court relied on [Big H’s invoices and other
documentation] without deducting the unreasonable amounts.”
¶33 The trial court rejected the Hales’ approach to overpayments and
underpayments for two reasons. First, the court stated that, “[u]nder basic accounting
principles, these debits and credits are netted‐out to reflect the actual financial effect to
the obligor and obligee, resulting in no damage to the owner.” Second, the court found
that the Hales’ expert’s presentation of the evidence cast “substantial doubt on the
credibility of his decision to suddenly include the ‘underpayments’ as a debit against
Big H.” Their expert’s initial report did not apply underpayments as a debit against
Big H. He did so, the court noted, only in reaction to a ruling of the court sixteen
months later, “as a way of trying to cushion a portion of the financial swing in Big H’s
favor from the Court’s ruling.”
¶34 We reject the Hales’ challenge for three independent reasons. First, the Hales
have not borne their burden as appellants of demonstrating that the law is on their side.
They cite no Utah authority, and while the foreign cases they cite deal with cost‐plus
contracts, they do not deal with underpayments or overpayments and thus do not
support the Hales’ contention. See Burdette v. Drushell, 2001‐2494, p. 8 (La. App. 1 Cir.
12/20/02), 837 So. 2d 54 (addressing the need to itemize costs to protect against claims
for vague or inflated costs); Metropolitan Elec. Co. v. Mel‐Jac Constr. Co., 576 P.2d 323,
325–26 (Okla. Civ. App. 1978) (examining a claim of overcharging, not overpayment).
Accordingly, the Hales have given us no reason to reject, as a matter of law, the trial
court’s approach.
¶35 Second, the Hales’ “undisputed evidence that certain invoices were underpaid or
overpaid” is the testimony of their expert witness. As noted above, the trial court
doubted the credibility of that witness. “Upon review, we accord deference to the trial
court’s ability and opportunity to evaluate credibility and demeanor.” State v. Goodman,
763 P.2d 786, 787 (Utah 1988); Iacono v. Hicken, 2011 UT App 377, ¶ 17, 265 P.3d 116(explaining that appellate courts “defer to the [trial] court’s determinations of the
weight to be placed on each witness’s testimony” because the trial court is “the arbiter
of witness credibility in a bench trial” (citing Lamkin v. Lynch, 600 P.2d 530, 531 (Utah
20100785‐CA 12
1979))). As the Hales’ counsel conceded at trial, without expert testimony “our case is
over.”
¶36 Third, the Hales have not demonstrated prejudice. As noted above, they make no
effort to refute Big H’s argument that any errors that do not in the aggregate exceed
$52,493 are harmless.
¶37 In sum, the Hales have not established that the trial court’s damage calculation
resulted in reversible error.
III. The Hales Have Not Shown a Right to an Offset for Unfinished Items.
¶38 The Hales also challenge the trial court’s finding that they are not entitled to an
offset for items allegedly left unfinished or in need of repair. In their Complaint, the
Hales alleged breach of contract by Big H for “failure to complete the Project as per the
terms of the [contracts]” and “failure to complete work on the Project in a good and
workmanlike manner[, which] further constitutes a substantial and material breach of
the [contracts].” They argue on appeal that the trial court should have offset Big H’s
damage award by the value of “warranty repair work” Big H allegedly failed to
provide.
¶39 This warranty repair work amounted to “punch list items” that were, according
to the Hales, left unfinished or in need of repair when Big H left the project in late 2004.
The Hales claimed that the punch list items totaled more than $73,000. They supported
their claim at trial with schedules prepared by their expert and with photographic
evidence of the alleged unfinished items. Their expert’s schedules contained estimated
values for each item claimed. The Hales contend that, because the trial court’s judgment
“failed to consider the cost of those repairs in its calculation, . . . [its judgment] is not
based on sufficient evidence.” They point out that “[n]o evidence whatever exists to
challenge” their expert’s figures on the value of the punch list items.
¶40 However, the trial court ruled that the Hales were not entitled to an offset. It
based this ruling on several grounds, including that Big H substantially complied with
the contract and that the Hales failed to prove damages.
20100785‐CA 13
A. Substantial Performance
¶41 “To establish a breach of contract claim, a party must identify a contracted duty
that the other party has breached.” Tooele Assocs. Ltd. Partnership v. Tooele City, 2011 UT
App 36, ¶ 2, 251 P.3d 835. The trial court concluded that the Hales did not prove that
Big H breached its contractual duty to complete the homes in a good and workmanlike
manner. Its conclusion was based on three key factual findings. First, based at least in
part on Dwayne Horsley’s testimony, the trial court found that “[Big H] repaired items
made known to them and there [was] no evidence that things were left incomplete or
completed improperly insofar as the items were known to them before December 1,
2004,” when the Hales breached the contract and Big H left the project. Second, the trial
court concluded that the parties’ contract required Big H to build the homes in
“‘substantial compliance’ with agreed‐upon plans and specifications.” Third, the trial
court found, “based upon all the testimony, that the Hales received the two [h]omes in
accordance with their plans and specifications, plus substantial upgrades and
modifications that they themselves requested,” and that “[a]ll of the allegedly defective
and/or incomplete work items . . . constitute minor punch list items.”
¶42 The Hales argue that Dwayne Horsley’s testimony, when “read in full,” does not
support these findings. Specifically, they argue that “he equivocated in some parts of
his testimony on the subject” by testifying that he had completed the punch list items
“‘to [his] knowledge,’” and that he was uncertain of or disputed three items on the list.
“On the other hand,” the Hales point out, Charles and Beverly Hale, their son, and
“both experts testified that there were items that still needed to be fixed.”
¶43 Our role is not to second‐guess the trial court’s assessment of witness credibility
based on the cold record on appeal. See State v. Pena, 869 P.2d 932, 936 (Utah 1994)
(explaining that trial court judges are “considered to be in the best position to assess the
credibility of witnesses and to derive a sense of the proceeding as a whole, something
an appellate court cannot hope to garner from a cold record”), holding modified by State v.
Levin, 2006 UT 50, 144 P.3d 1096; Sorenson v. Kennecott‐Utah Copper Corp., 873 P.2d 1141,
1147 (Utah Ct. App. 1994) (noting the “well‐settled principle that an appellate court will
not second‐guess a trial court on issues of witness credibility”). As noted above, one of
the Hales’ obstacles on appeal is the trial court’s assessment of the credibility of its
principal witnesses, specifically, Charles Hale and the Hales’ expert. Although this
credibility determination undermines their warranty claim, the Hales do not discuss it
20100785‐CA 14
on appeal. More importantly, they do not specifically challenge the trial court’s findings
that Big H substantially complied with the parties’ contract and that the homes Big H
constructed complied with the plans and specifications, including upgrades and
modifications the Hales requested.
¶44 In sum, the Hales have not demonstrated that the trial court’s findings with
respect to the warranty repair work are clearly erroneous.
B. Proof of Damages
¶45 Proof of damages is an element of a claim for breach of contract. See Bair v. Axiom
Design, LLC, 2001 UT 20, ¶ 14, 20 P.3d 388. The Hales’ expert provided estimates of the
cost of the repair work, and the Hales assert that “[n]o evidence whatever exists to
challenge [their expert]’s figures on the cost of repairs.” But the trial court found that
the Hales’ expert’s value estimates for the allegedly unfinished or damaged items were
not reliable. Inasmuch as the expert himself labeled the amounts on the punch list as
“‘estimates,’ and acknowledged at trial that they were less accurate and precise” than
other schedules the court found to be “riddled with numerous substantive flaws,” the
court found “little . . . to credit in [the Hales’ expert’s estimates of the repair work].” The
Hales have not challenged this credibility determination. Instead, they argue that the
trial court erred by “dismiss[ing their expert’s] figures as ‘estimates,’” because “where a
breach is found, and no contrary evidence is presented, damages are to be quantified in
whatever method is reasonable; mathematical precision is not required.” (Emphasis
added.) Even if the Hales could successfully challenge the trial court’s finding that
Big H substantially complied with the contract—which they have not—their argument
is unavailing. The trial court found not that the Hales’ evidence was insufficient because
the values were estimated, but that their expert’s estimates were not reliable. The Hales
have not demonstrated error in this regard.
IV. The Hales Have Not Shown that the Trial Court Erred by Including the Cost of the
Land in the Fee Calculation.
¶46 The Hales contend that the trial court erred by permitting Big H to recover profit
on the cost of the land for the Lot 45 home because doing so contravenes the Utah Real
Estate Licensing and Practices Act (the Act), see Utah Code Ann. §§ 61‐2‐1 to ‐24 (Lexis
Publishing 2000) (current version at id. §§ 61‐2f‐101 to ‐512 (LexisNexis 2011 & Supp.
20100785‐CA 15
2012)). They argue that including the cost of the Lots is “improper as a matter of law
because, under [the Act], only licensed agents and brokers may take commissions on
the sale of real estate.” According to the Hales, “[b]ecause there is no finding and no
evidence that Big H or Dwayne Horsley were licensed real estate agents or brokers,
neither is entitled to recover a commission on the cost of the lots.”6
¶47 Big H responds that “the parties’ course of conduct recognized that the price of
the [Lots] was among the costs on which Big H’s 10% fee was to be based.” In other
words, the portion of the builder’s fee that was based on the cost of the Lots was indeed
a builder’s fee, not a commission on the sale of land as defined by the Act. The trial
court ruled, “Neither Big H nor anyone else is claiming that the Hales owe such a
commission as part of their acquisition of Lot 45 from [Triple Crown Estates]. Rather,
Big H is simply claiming that the price of the land, i.e., its cost—once it has been
acquired—is a ‘Cost’ on which its agreed‐upon fee is to be paid.”
¶48 The Act generally governs who may recover commissions on the sale of real
estate. See Sachs v. Lesser, 2008 UT 87, ¶¶ 11–12, 207 P.3d 1215 (discussing a later but
substantively similar version of the Act). Specifically, section 61‐2‐18 of the Act places
limits on who may file suit to recover commissions for certain actions:
No person may bring or maintain an action in any court of
this state for the recovery of a commission, fee, or
compensation for any act done or service rendered which is
prohibited under this chapter to other than licensed
principal brokers, unless the person was duly licensed as a
principal broker at the time of the doing of the act or
rendering the service.
Utah Code Ann. § 61‐2‐18(1) (Lexis Publishing 2000) (current version at id. § 61‐2f‐409(1)
(LexisNexis 2011)). Under section 61‐2‐4, an act “for valuable consideration, of buying,
[or] selling . . . real estate for another, . . . requires the person performing . . . the act to
be licensed as a principal real estate broker, an associate real estate broker, or a real
6. The Hales’ claim is based on statute, not contract. They have not asserted that the
meaning of “Costs” in the cost‐plus contract with Big H was ambiguous, nor have they
asked us to review the trial court’s reading of the term as used in the contract.
20100785‐CA 16
estate sales agent as set forth in this chapter.” Id. § 61‐2‐4 (Lexis Publishing 2000)
(current version at id. § 61‐2f‐201(2) (LexisNexis 2011)).
¶49 Here, Big H included the cost of Lot 45 in the Costs of the finished home built on
that lot for purposes of calculating its ten percent fee. The question raised on appeal,
then, is whether that portion of Big H’s builder’s fee was—as Big H maintains—a fee for
building the home or—as the Hales maintain—a real estate sales commission. The
Hales’ briefing of this question consists of four sentences, one of which asserts a
violation of the Act, one of which asserts the uncontested fact that neither Big H nor
Dwayne Horsley were licensed real estate brokers or agents, and two of which quote
the statutory subsections cited above. Their reply brief adds the assertion that “[a]
simple reading of the plain language of the Licensing Act makes it clear that Defendants
cannot claim a commission on the cost of the lots.”
¶50 We do not agree that the issue is so plain from the language of the statutes as to
require no analysis on the facts presented here. The text of the relevant provisions does
not contemplate the situation these parties find themselves in. Application of the law to
the facts thus requires some connective tissue. The duty to supply it falls on the party
claiming error.
¶51 An adequately briefed argument must “contain the contentions and reasons of
the appellant with respect to the issues presented, including the grounds for reviewing
any issue not preserved in the trial court, with citations to the authorities, statutes, and
parts of the record relied on.” Utah R. App. P. 24(a)(9). Case law applying this rule
makes clear that it “‘requires not just bald citation to authority but development of that
authority and reasoned analysis based on that authority.’” State v. Green, 2004 UT 76,
¶ 13, 99 P.3d 820 (quoting State v. Thomas, 961 P.2d 299, 305 (Utah 1998)). Citing relevant
provisions and cases without “any meaningful analysis of this authority” falls short.
State v. Jaeger, 1999 UT 1, ¶ 31, 973 P.2d 404. The Hales have presented no more here.
We accordingly conclude that this claim of error is inadequately briefed and we reject it
on that ground.7
7. In addition, the most analogous case our own research has disclosed casts doubt on
the Hales’ claim. Sachs v. Lesser, 2008 UT 87, 207 P.3d 1215, addressed whether a finder’s
fee for the sale of a business whose “only asset of significance was its real property”
(continued...)
20100785‐CA 17
¶52 The Hales make two additional arguments on appeal for why we should reverse
the trial court’s ruling on this issue. First, they argue that inclusion of the land as a cost
violates the Statute of Frauds in this case. The trial court rejected this argument “for the
reasons set forth in Big H’s written opposition [to the motion for new trial and to amend
the judgment].” Among those reasons was that the Hales’ claim was waived. We agree
that it was.
¶53 Rule 8(c) of the Utah Rules of Civil Procedure requires a party to plead
affirmative defenses in its responsive pleading. The rule explicitly includes the Statute
of Frauds defense. See Utah R. Civ. P. 8(c). Subject to exceptions not applicable here,
defenses not properly pleaded are waived. See Utah R. Civ. P. 12(h) (“A party waives all
defenses and objections not presented either by motion or by answer or reply . . . .”);
City Elec. v. Dean Evans Chrysler–Plymouth, 672 P.2d 89, 90 (Utah 1983) (declining to
consider a Statute of Frauds defense when the party failed to raise it at trial).
¶54 The Hales did not raise the Statute of Frauds until their objection to Big H’s
proposed findings of fact and conclusions of law and their motion for new trial—well
after having answered Big H’s counterclaims without pleading the Statute of Frauds as
an affirmative defense, and more than five years into the case. The Hales persuasively
argue that they could not have foreseen Big H’s damage calculation at the pleadings
stage. But they offer no explanation for withholding this defense until their post‐trial
motion. Accordingly, we conclude that the Hales waived this affirmative defense at trial
and we decline to address it now. See City Elec., 672 P.2d at 90.
7. (...continued)
was a transaction governed by the Act. See id. ¶ 3. The court noted that the Act “defines
real estate as ‘includ[ing] leaseholds and business opportunities involving real
property.’” Id. ¶ 12 (alteration in original) (quoting Utah Code Ann. § 61‐2‐2(14) (2006)).
The court held that “[a] transaction in which the transfer of real estate is the dominant
feature of the exchange, and not merely incidental to the sale of a business, is a sale of
real estate governed by the provisions of [the Act].” Id. ¶ 24. Here, our review of the
record suggests that the cost of Lot 45 accounted for $134,500, or about eight percent, of
total Costs of $1,721,000. These numbers suggest that this deal was not one “in which
the transfer of real estate”—as opposed to the construction of a home—was “the
dominant feature of the exchange” and therefore “a sale of real estate governed by the
provisions of [the Act].” See id.
20100785‐CA 18
¶55 The Hales also argue that inclusion of the land as a Cost contravenes the Utah
Mechanics’ Lien statute, see Utah Code Ann. §§ 38‐1‐1 to ‐37 (LexisNexis 2005) (current
version at id. §§ 38‐1a‐101 to ‐804 (LexisNexis Supp. 2012)). This argument was not
preserved. To preserve an issue for appellate review, a party must raise the issue at trial
in a timely, specific fashion and introduce supporting evidence or relevant legal
authority in order to “put the [trial court] on notice of the asserted error” so that the
trial court has an opportunity to correct it. O’Dea v. Olea, 2009 UT 46, ¶ 18, 217 P.3d 704(citation and internal quotation marks omitted); see also Utah R. App. P. 24(a)(5)(A)–(B)
(requiring appellant’s brief to provide either a “citation to the record showing that the
issue was preserved in the trial court” or “a statement of grounds for seeking review of
an issue not preserved”). We find no mention in the record of this argument, and the
Hales have not pointed us to any. Because the Hales did not raise this issue at trial, they
did not preserve it. Because they did not preserve it, we decline to consider it. See
Bangerter v. Poulton, 663 P.2d 100, 102 (Utah 1983) (“It is axiomatic that defenses and
claims not raised by the parties in the trial cannot be considered for the first time on
appeal.”).
V. The Hales Have Not Shown that James Horsley Had Authority to Accept
a $30,000 Payment for Big H.
¶56 The Hales contend that the trial court erred by not giving them credit for $30,000
they paid to James Horsley in November 2004. They argue that James Horsley had
authority to accept payment on Big H’s behalf, and that the Hales intended the
November 2004 payment to be a payment to Big H. According to the Hales, “[i]t was
both within the apparent and actual scope of James [Horsley’s] authority to receive a
builder’s profit payment from the Hales, and the trial court erred in failing to credit that
payment to the Hales.”
A. Actual Authority
¶57 “Under agency law, an agent cannot make its principal responsible for the
agent’s actions unless the agent is acting pursuant to either actual or apparent
authority.” Zions First Nat’l Bank v. Clark Clinic Corp., 762 P.2d 1090, 1094 (Utah 1988).
Actual authority may be express or implied:
20100785‐CA 19
Actual authority incorporates the concepts of express and
implied authority. Express authority exists whenever the
principal directly states that its agent has the authority to
perform a particular act on the principal’s behalf. Implied
authority, on the other hand, embraces authority to do those
acts which are incidental to, or are necessary, usual, and
proper to accomplish or perform, the main authority
expressly delegated to the agent.
Id. (citations omitted). As its name suggests, implied authority “may be implied from
the words and conduct of the parties and the facts and circumstances attending the
transaction in question.” Id. at 1095.
¶58 The trial court found that James Horsley did not have actual authority to receive
payments on behalf of Big H based on two findings: that James Horsley was not an
officer, director, or management employee of the corporation; and that, as Dwayne
Horsley testified, neither he nor Big H ever delegated this authority to James Horsley.
¶59 The Hales argue that both findings are clearly erroneous. They point out that
both James Horsley and Dwayne Horsley testified that they had an agreement to
equally divide the profit on the Hales’ homes. In addition, Dwayne Horsley testified
that James Horsley acted as “foreman” on the project, and James Horsley testified that
he performed “project management” duties. Given this evidence, the Hales argue, “it is
clearly erroneous to imply that James [Horsley] was not authorized to receive from the
Hales a portion of the builder’s fee.”
¶60 We acknowledge that the trial court had before it evidence that reasonably
supported both the Hales’ and Big H’s conflicting accounts. However, when, as here,
“there is conflicting evidence, we defer to the trial court as the factfinder. The existence
of conflicting evidence does not give rise to clear error as long as evidence supports the
trial court’s decision.” Gardner v. Madsen, 949 P.2d 785, 790 (Utah Ct. App. 1997)
(citation omitted). We think the record adequately supports the trial court’s finding that
James Horsley did not have actual authority to accept payment on Big H’s behalf.
¶61 The record lacks any evidence that James Horsley appears in Big H records
maintained by the Utah Division of Corporations. Dwayne Horsley testified that James
Horsley was “just a foreman basically,” managing work “[o]ff and on,” and that James
20100785‐CA 20
Horsley “[n]ever” accepted payments on behalf of Big H from the Hales. In addition, at
trial, James Horsley testified that he was a “representative” of Big H but that the Hales
“knew all along” that he was not an employee, “other than [he] was doing a service for
Big H,” that he “helped out” with the Hales’ project, and that he served as a foreman
“in a way.”
¶62 Furthermore, at the time that the Hales gave James Horsley the check for $30,000,
there were, as the trial court described, “enormous tensions” between Dwayne and
James Horsley “that had led to numerous arguments between them.” James Horsley
used the $30,000—with full knowledge of the Hales—for a personal investment in a
mortgage company, unrelated to Big H or the Hale project. James Horsley testified that
he did not inform Big H or Dwayne Horsley when he received the check from the
Hales. When asked at trial whether he had informed Dwayne, James answered, “No. . . .
It had nothing to do with him.” Thus, even if the Hales could establish that James
Horsley had some kind of express authority as a “representative” or “foreman,” this
evidence undermines the claim that, based on “the facts and circumstances attending
the transaction in question,” see Zions First Nat’l Bank, 762 P.2d at 1095, James Horsley
had authority to accept payment from the Hales on Big H’s behalf.
¶63 In light of the evidence supporting the trial court’s conclusion, the Hales have
not demonstrated that the trial court clearly erred in concluding that James Horsley
lacked actual authority to accept payment on Big H’s behalf.
B. Apparent Authority
¶64 Apparent authority exists where the conduct of the principal causes a third party
to reasonably believe that someone has authority to act on the principal’s behalf, and
the third party relies on this appearance of authority and will suffer loss if an agency
relationship is not found. Luddington v. Bodenvest Ltd., 855 P.2d 204, 209 (Utah 1993);
Posner v. Equity Title Ins. Agency, Inc., 2009 UT App 347, ¶ 18, 222 P.3d 775. “Thus, an
analysis of apparent authority focuses on the acts of the principal from a third party’s
perspective.” Posner, 2009 UT App 347, ¶ 18 (citation and internal quotation marks
omitted).
¶65 The Hales contend that the trial court erred in ruling that James Horsley lacked
apparent authority to receive the payment, and that “some of the factual findings
supporting [that conclusion] are clearly erroneous.” First, the Hales argue that Big H
20100785‐CA 21
created an appearance that James Horsley had authority. They point out that James
Horsley accepted reimbursement for $4,000 of construction expenses from the Hales on
at least one prior occasion and “there is no evidence that Big H rejected or disgorged
that payment,” and that “James Horsley also testified that he ‘received a couple of
checks payable to James Horsley’ as reimbursement for the construction.”
¶66 Second, the Hales argue that they reasonably believed, based on the appearance
Big H created, that James Horsley had authority to receive the payment. They argue,
“[T]he Hales understood that James [Horsley] was Dwayne[ Horsley]’s ‘partner’ in
Big H and that he was a representative of it.” Indeed, they assert, both brothers testified
that James Horsley “was a representative of Big H.” The Hales point out that Big H
entered into an agreement with James Horsley to divide the profits on the Hales’
homes, an act on the part of Big H that made it reasonable for the Hales to believe that
James Horsley had authority to accept payment for Big H.
¶67 Finally, the Hales argue that they relied on this appearance of authority and will
suffer loss if they do not receive a credit equal to the $30,000 payment. They argue, “[I]t
is undisputed that the Hales paid James [Horsley] $30,000, he has not paid it back, and
the trial court did not credit [the Hales] for that payment.”
¶68 Based on the evidence, the Hales contend that “the court’s legal conclusion” that
James Horsley lacked apparent authority “is in error because the factual findings do not
properly consider the factors that would support a ruling of apparent authority.”
¶69 We disagree. First, the trial court properly considered whether Big H’s “acts or
conduct” created an appearance that James Horsley had authority to accept payment on
Big H’s behalf. See Posner v. Equity Title Ins. Agency, Inc., 2009 UT App 347, ¶ 18, 222
P.3d 775 (citation and internal quotation marks omitted). The trial court found no
evidence that Dwayne Horsley ever told the Hales, or otherwise led them to believe,
that James Horsley had such authority. For the court to find apparent authority, “[i]t is
the principal who must cause [the third party] to believe that the agent is clothed with
apparent authority.” City Elec. v. Dean Evans Chrysler–Plymouth, 672 P.2d 89, 90 (Utah
1983). The Hales challenge this finding largely by pointing to evidence that James
Horsley—the alleged agent—accepted payments from the Hales.
20100785‐CA 22
¶70 The trial court properly considered facts relevant to the Hales’ reasonable
perspective (as a third party) of James Horsley’s authority. The trial court found that it
was “unreasonable for the Hales to have expected James [Horsley] to apply the $30,000
check to Big H’s account.” For example, the Hales knew that James Horsley intended to
use the funds for a separate business venture that did not involve Big H. The Hales
were aware that their delay in paying the builder’s fee had created “enormous tensions
between” Dwayne Horsley and James Horsley. Moreover, the Hales made the check
payable to James Horsley without designating Big H as a joint payee or even notifying
Dwayne Horsley or Big H of the payment prior to filing the lawsuit, despite the fact
that, as the trial court described it, “they were in an adversarial relationship with Big H,
making it incumbent upon them to clearly inform Big H of the payment.” Finally, the
Hales “had never, in the entire history of their . . . family business, issued to an
individual”—such as James Horsley—“a check intended for a business entity
creditor”—such as Big H.
¶71 Once again, we acknowledge that the trial court had before it evidence that
reasonably supported both the Hales’ and Big H’s conflicting accounts. However, we
grant broad deference to the trial court’s application of the doctrine of apparent
authority to the facts of the case. Glew v. Ohio Sav. Bank, 2007 UT 56, ¶ 19, 181 P.3d 791.
Where, as here, “the trial court’s findings include inferences drawn from the evidence,”
we defer to the trial court “unless the logic upon which [its] extrapolation from the
evidence is based is so flawed as to render the inference clearly erroneous.” Id. ¶ 18.
Here it was not. We therefore decline to disturb the trial court’s ruling that the Hales are
not entitled to a credit for the $30,000 payment to James Horsley.
VI. The Hales Have Not Shown that Big H Violated the Mechanics’ Lien Statute.
¶72 The Mechanics’ Lien statute imposes criminal and civil liability on “[a]ny person
entitled to record or file a lien . . . who intentionally causes a claim of lien against any
property, which contains a greater demand than the sum due to be recorded or filed.”
See Utah Code Ann. § 38‐1‐25 (LexisNexis 2005) (current version at id. § 38‐1a‐308
(LexisNexis Supp. 2012)).8 A person who violates the provision “is liable to the owner of
8. The Mechanics’ Lien statute has been renamed as the Preconstruction and
Construction Liens statute. We cite the version of the statute in effect at the time of the
(continued...)
20100785‐CA 23
the property” for either “twice the amount by which the wrongful lien exceeds the
amount actually due,” or “the actual damages incurred.” Id. § 38‐1‐25(2).
¶73 The Hales contend that the trial court erred in finding that neither Big H nor
Dwayne Horsley is liable for damages for abuse of a lien right under the statute. To
prove a claim for abuse of a lien right, the Hales must show as a threshold matter that
the lien contained a “greater demand than the sum” actually owed. See id. § 38‐1‐25(1).
They assert that the amount of the lien was excessive by the full face amount of the lien
because the Hales “actually overpaid” Big H. Therefore, “it is axiomatic that the lien
filed by [Big H,] . . . asserting a right to an addition[al] payment in the amount of
$165,000, was high by $165,000.” But, according to the Hales, even if a proper
accounting showed that the Hales owe Big H some amount of money, Big H is still
liable under section 38‐1‐25(2) because the information that Horsley testified that he had
relied on in preparing the lien did not establish, “or even giv[e] a reasonable forecast of,
the face amount of the lien” at the time. Therefore, the Hales argue that in authorizing
the lien, Dwayne Horsley and Big H “sought to cloud [the] Hales’ title to Lot 45 in order
to extract from them an amount more than was due, and otherwise to procure an
unjustified advantage or benefit.”
¶74 The trial court found, “Based upon a review of all invoices, . . . the lien amount
filed by [Dwayne Horsley on behalf of Big H] reflected less than the balance [the Hales]
actually owed.” Therefore, the trial court concluded that the $165,000 mechanics’ lien
that Big H filed against the Lot 45 home was valid. See Utah Code Ann. § 38‐1‐3
(LexisNexis 2005) (current version at id. § 38‐1a‐301 (LexisNexis Supp. 2012))
(authorizing liens “for the value of the service rendered, labor performed, or materials
or equipment furnished or rented”). Because the Hales have not shown that the trial
court’s damages calculation was clearly erroneous, see supra Part II, they have not
shown error in the court’s finding that the lien was valid. Because the lien was valid,
neither Big H nor its employee, Dwayne Horsley, violated Utah Code section 38‐1‐25(1)
for abuse of a lien right. Because neither violated section 38‐1‐25(1), neither is liable to
the Hales under section 38‐1‐25(2). We therefore affirm the trial court’s ruling on the
Hales’ abuse of lien claim.
8. (...continued)
alleged wrongful lien.
20100785‐CA 24
CONCLUSION
¶75 In sum, the Hales have not shown reversible error. The trial court did not err as a
matter of law when it considered the evidence Big H provided, along with expert and
lay testimony, in calculating Costs. Nor have the Hales shown that the trial court’s
inclusion of the cost of the land was an error of law. They have not shown that the trial
court’s findings were clearly erroneous regarding expenses and payments, the Hales’
claim for an offset for warranty repair work, or James Horsley’s lack of actual or
apparent authority. Finally, they have not shown that the trial court erred in ruling that
neither Dwayne Horsley nor Big H violated the mechanics’ lien statute. At trial, the
court considered “a sizeable mass of evidence that [it] was required to sift and weigh in
aid of reaching a lawful result.” See Traco Steel Erectors, Inc. v. Comtrol, Inc., 2009 UT 81,
¶ 20, 222 P.3d 1164. The trial court acted within its discretion in weighing the relative
credibility of that evidence, and its rulings find sufficient factual support in the record.
Accordingly, we decline the Hales’ invitation to second‐guess those factual findings on
appeal. Affirmed.
____________________________________
J. Frederic Voros Jr., Judge
‐‐‐‐‐
¶76 WE CONCUR:
____________________________________
William A. Thorne Jr., Judge
____________________________________
Stephen L. Roth, Judge
20100785‐CA 25